Douglas County News Press 0207 by Colorado Community Media

February 7, 2019 The Sterling Ranch Community Authority Board,

an authority and separate legal entity formed pursuant to §29-1-203.5, C.R.S. (hereinafter called the “Owner”) will receive sealed Bids for the Sterling Ranch – Providence Village Recreation Center (collectively the “Project”) at Redland located at 1500 West Canal Court, Littleton, CO 80120 until 12:30 P.M., March 1, 2019. Bids not provided to Redland on or before 12:30 P.M. on March 1, 2019, may be provided, in hard-copy format and sealed, at the time and place of bid opening. Bids received will be publicly opened and read aloud at Brownstein Hyatt Farber Schreck, LLP, located at 410 Seventeenth Street, Suite 2200, Denver, CO 80202, at 2:00 P.M. March 1, 2019.

Bids and Settlements

A description of the Work to be performed is: Sterling Ranch Providence Village Commercial Recreation Center Improvements located in Douglas County, Colorado. This work will consist of construction and erection of a 6000 SQ FT recreation center (4900 sq ft finished) and adjacent foundation excavation and backfill improvements within 5 feet of the building. The structure consists of 2 stories-heated, wood frame, elevator, warming kitchen only, and changing room. This contract will not include pool facilities, landscape, additional grading, or utility work. Bidders shall bid on all of this project scope as further defined in the construction documents. The contract will be awarded in whole for the areas of construction described above. Bid packages will be available for download the day of advertisement on February 7, 2019 at the following link: https://redland.box.com/s/lhtg8jo2vwvakc8kp3o hu6e7gbbsbxu0 Plan holders are required to notify Wade LePlatt and Alec Garbini via email and phone that they are plan holders, no later than four (4) days prior to bid submissions, in order to receive notification of bid addenda. Bidders must acknowledge receipt of bid addenda on the designated form with their bid submission or their bid will be automatically disqualified. A pre-bid conference will not be held. Bids shall be made on the bid forms furnished by the Owner and shall be enclosed in a sealed envelope and endorsed with the name of the Bidder along with an electronic Excel copy on disk or thumb drive. A Bid Bond in an amount equal to five percent (5%) of the total Bid amount will be required. The Bid Bond will be retained by Owner as liquidated damages should the Successful Bidder fail to enter into a Contract with the Owner in accordance with the Bid. Bidders must supply a list of Subcontractors. Attention is called to the fact that Bidders offer to assume the obligations and liabilities imposed by the Contract Documents. The Successful Bidder for the Project will be required to furnish a Performance Bond and a Labor and Materials Payment Bond and a Warranty Bond of the full amount (100%) of the Agreement Price, in conformity with the requirements of the Contract Documents. Bidders are hereby advised that the Owner reserves the right to not award a Contract until sixty (60) days from the date of the opening of the Bids, and Bidders expressly agree to keep their Bids open for the sixty (60) day time period. Owner reserves the right to reject any and all Bids, to waive any informality, technicality or irregularity in any Bid, to disregard all non-conforming, non-responsive, conditional or alternate Bids, to negotiate contract terms with the Successful Bidder, to require statements or evidence of Bidders’ qualifications, including financial statements, and to accept the proposal that is in the opinion of the Owner in its best interest. Owner reserves the right to accept any combination of Bids which in Owner’s sole, and absolute judgment will, under all circumstances, best serve the Owner’s interests. Owner also reserves the right to extend the Bidding period by Addendum if it appears in its best interest to do so. Any questions concerning this bid shall be directed via email to: Alec Garbini Phone: 303-907-5489 Email: garbinisan@aol.com AND Wade LePlatt, Redland 1500 West Canal Court Littleton, CO 80120 Phone: 720-283-6783 ext. 134 Email: wleplatt@redland.com Legal Notice No.: 934752 First Publication: February 7, 2019 Last Publication: February 7, 2019 Publisher: Douglas County News-Press Public Notice NOTICE TO BIDDERS

Separate sealed bids for the 2019 Townwide Chip Seal-Slurry Program (CIP 19-005) as described in the CONTRACT DOCUMENTS, will be received by the Town of Parker, Department of Public Works, located at 20120 E. Mainstreet, Parker, CO 80138, until 11:00 a.m. local time, February 21, 2019, and then at said office publicly opened and read aloud.

Construction plans, specifications and forms for preparing bids may be obtained at the office of the Town of Parker, Department of Public Works, 20120 E. Mainstreet, Parker, CO 80138, on or after 9:00 a.m., January 31, 2019, and upon payment of $40.00 per each set, (non-refundable) payable to the Town of Parker or you may obtain an electronic document by calling the Public Works Department at #303.840.9546.

All bids must be accompanied by a certified check payable to the Town of Parker in an amount of at least five percent (5%) of the Bid, drawn on a bank which is a member of the Federal Reserve System, or a Bidders bond in the same amount. The check or bond will be retained by the Town as liquidated damages if the successful bidder refuses or fails to enter into a Contract and Performance, Payment and Maintenance bond in accordance with his bid when notified of the award.

the Public Works Department at #303.840.9546. All bids must be accompanied by a certified check payable to the Town of Parker in an amount of at least five percent (5%) of the Bid, drawn on a bank which is a member of the Federal Reserve System, or a Bidders bond in the same amount. The check or bond will be retained by the Town as liquidated damages if the successful bidder refuses or fails to enter into a Contract and Performance, Payment and Maintenance bond in accordance with his bid when notified of the award.

Bids and Settlements

The Town shall issue a written addendum if substantial changes which impact the technical submission of Bids are required. Addenda will be posted on the Town of Parker eTrakit website (https://lms.parkeronline.org/etrakit3/). Plan Holders are responsible for either revisiting website prior to the due date or contacting the Public Works Department at (303.840.9546) to ensure that they have any addenda which may have been issued after the initial download. The Plan Holder shall certify its acknowledgment of the addendum by signing the addendum and returning it with its Bid. In the event of conflict with the original contract documents, addenda shall govern all other contract documents to the extent specified. Subsequent addenda shall govern over prior addenda only to the extent specified. The extent of the work is approximately as follows: This contract consists of but not limited to placing approximately 64,000 square yards of Type 1 cover coat material with fog seal, 489,000 square yards of Type II slurry seal, concrete removal and replacement including all associated traffic control and replacement pavement markings. Bids may not be withdrawn for a period of fortyfive (45) days after the time fixed for closing them. The Owner reserves the right to waive irregularities, to waive technical defects accordingly as the best interest of the Town may be served, may reject any and all bids, and shall award the contract to the lowest responsible bidder as determined by the Owner. All bidders questions and inquires shall be directed to the Town of Parker’s Project Manager, John Mounier, (303) 805-3216. Tom Williams, PE, Engineering/Public Works Director This Notice to Bidders is not valid without the above signature. NOTICE TO NONRESIDENT BIDDERS The purpose of this notice is to comply with C.R.S. § 8-19-104(3). If a nonresident bidder is from a state that provides a bidding preference to bidders from that state, then a comparable percentage disadvantage will be applied to the bid of that nonresident bidder. Nonresident bidders may obtain additional information from the Web site for the Colorado Department of Labor and Employment. Legal Notice No.: 934753 First Publication: February 7, 2019 Last Publication: February 7, 2019 Publisher: Douglas County News-Press Public Notice NOTICE OF FINAL PAYMENT NOTICE IS HEREBY GIVEN that the City of Lone Tree of Douglas County, Colorado will make final payment at the offices of City of Lone Tree at or after four-o’clock (4:00) p.m. on Tuesday, February 19, 2019 to Colorado Barricade Co. for all work done by said CONTRACTOR for the 2018 Striping Project. The project provided for the striping of various City streets being within or near the boundaries of the City of Lone Tree, in the County of Douglas, State of Colorado. Any person, co-partnership, association of persons, company, or corporation that has furnished labor, materials, provisions, or other supplies used or consumed by such CONTRACTOR or his Subcontractor(s), in or about the performance of the work contracted to be done and whose claim, therefore, has not been paid by the CONTRACTOR or his Subcontractor(s) at any time, up to and including the time of final settlement for the work contracted to be done, is required to file a verified statement of the amount due and unpaid on account of such claim to the City of Lone Tree, 9220 Kimmer Drive, Colorado 80124 at or before the time and date hereinabove shown. Failure on the part of any claimant to file such verified statement of claim prior to such final settlement will release said City of Lone Tree, its City Council Members, officers, agents, consultants, and employees of and from any and all liability for such claim. BY ORDER OF THE CITY COUNCIL CITY OF LONE TREE, COLORADO By: Lisa A. Albers, Public Works Manager Legal Notice No.: 934712 irst Publication: January 31, 2019 ast PUblication: February 7, 2019 ublisher: Douglas County News-Press

Summons and Sheriff Sales Public Notice District Court, COUNTY OF DOUGLAS, STATE OF COLORADO CIVIL ACTION NO. 2018CV30730, Division/Courtroom # 5 SHERIFF’S SALE NO. 19000028 NOTICE OF SHERIFF'S SALE OF REAL PROPERTY THE VILLAGES OF PARKER MASTER ASSOCIATION, Plaintiff: v.

District Court, COUNTY OF DOUGLAS, STATE OF COLORADO CIVIL ACTION NO. 2018CV30730, Division/Courtroom # 5 SHERIFF’S SALE NO. 19000028

Summons and Sheriff Sales NOTICE OF SHERIFF'S SALE OF REAL PROPERTY

THE VILLAGES OF PARKER MASTER ASSOCIATION, Plaintiff: v. SIMON J. OVENS, Defendant(s) Regarding: Lot 29A, Villages of Parker Filing No. 30 1st Amendment, County of Douglas, State of Colorado; also known as: 23005 York Ave Parker, CO 80138 (the “Property”)

and best bidder will have two hours following the sale to tender the full amount of their bid, or they will be deemed to have withdrawn their bid. BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS SUFFICIENT TO COVER THE INITIAL BID AT THE TIME OF SALE.

Summons and Sheriff Sales

PLEASE NOTE THAT THE JUDGMENTS BEING FORECLOSED MAY NOT BE A FIRST LIEN ON THE SUBJECT PROPERTY. Recorded Transcripts of Judgement are in the amount of $7,901.75 All telephone inquiries for information should be directed to the office of the undersigned Sheriff at 303-660-7527. The name, address and telephone number of the attorney representing the legal owner of the above described lien is THE DUPONT LAW FIRM LLC PO BOX 1073 Castle Rock, CO 80104,720-644-6115

Under a Judgement and Decree of Foreclosure entered on December 12, 2018, relating to Transcripts of Judgments recorded in the Douglas County public records the undersigned is ordered to sell certain real property set forth and described above.

Dated January 17, 2019, Castle Rock, CO Tony Spurlock Sheriff of Douglas County, Colorado

TO THE ABOVE-NAMED DEFENDANTS, please take notice:

Legal Notice No.: 934660 First Publication: 1/17/2019 Last Publication: 2/14/2019 Published In: Douglas County News Press

You and each of you are hereby notified that a Sheriff's Sale of the referenced property is to be conducted by the Civil Division of the Sheriff's Office of Douglas County, Colorado at 10:00 A.M., on the 7th day March, 2019, at 4000 Justice Way, Suite 2213, Castle Rock, CO 80109, phone number 303-660-7527. At which sale, the above described real property and improvements thereon will be sold to the highest bidder. Plaintiff makes no warranty relating to title, possession, or quiet enjoyment in and to said real property in connection with this sale. All bidders will be required to have in their possession cash or certified funds at least equal to the amount of the judgment creditor’s bid. Please telephone 303-660-7527 prior to the sale to ascertain the amount of this bid. The highest and best bidder will have two hours following the sale to tender the full amount of their bid, or they will be deemed to have withdrawn their bid. BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS SUFFICIENT TO COVER THE INITIAL BID AT THE TIME OF SALE. PLEASE NOTE THAT THE JUDGMENTS BEING FORECLOSED MAY NOT BE A FIRST LIEN ON THE SUBJECT PROPERTY. Recorded Transcripts of Judgement are in the amount of $3,608.50 All telephone inquiries for information should be directed to the office of the undersigned Sheriff at 303-660-7527. The name, address and telephone number of the attorney representing the legal owner of the above described lien is ALCOCK LAW GROUP 19751 E MAINSTREET 210 Parker, CO 80138, 303-993-5400 Dated January 17, 2019, Castle Rock, CO Tony Spurlock Sheriff of Douglas County, Colorado Robert Rotherham, Deputy Douglas County, Colorado Legal Notice No.: 934655 First Publication: 1/17/2019 Last Publication: 2/14/2019 Published In: Douglas County News Press

Misc. Private Legals Public Notice DOUGLAS COUNTY DISTRICT COURT STATE OF COLORADO 4000 Justice Way Castle Rock, CO Douglas County, CO 80109 THE PEOPLE OF THE STATE OF COLORADO In the Interest of: SELENA DECIDERIO, D.O.B.: 7/7/2009; ROSA TORREZ, D.O.B.: 4/3/2002; JESSICA GONZALEZ, D.O.B.: 12/6/2001, Children,

Under a Judgement and Decree of Foreclosure entered on December 20, 2018, relating to Transcripts of Judgments recorded in the Douglas County public records the undersigned is ordered to sell certain real property set forth and described above. TO THE ABOVE NAMED DEFENDANTS, Please take notice: You and each of you are hereby notified that a Sheriff's Sale of the referenced property is to be conducted by the Civil Division of the Sheriff's Office of Douglas County, Colorado at 10:00 A.M., on the 7th day March, 2019, at 4000 Justice Way, Suite 2213, Castle Rock, CO 80109, phone number 303-660-7527. At which sale, the above described real property and improvements thereon will be sold to the highest bidder. Plaintiff makes no warranty relating to title, possession, or quiet enjoyment in and to said real property in connection with this sale. All bidders will be required to have in their possession cash or certified funds at least equal to the amount of the judgment creditor’s bid. Please telephone 303-660-7527 prior to the sale to ascertain the amount of this bid. The highest and best bidder will have two hours following the sale to tender the full amount of their bid, or they will be deemed to have withdrawn their bid. BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS SUFFICIENT TO COVER THE INITIAL BID AT THE TIME OF SALE. PLEASE NOTE THAT THE JUDGMENTS BEING FORECLOSED MAY NOT BE A FIRST LIEN ON THE SUBJECT PROPERTY. Recorded Transcripts of Judgement are in the amount of $7,901.75

Dated: 1/24/2019 /s/ R. LeeAnn Reigrut R. LeeAnn Reigrut, #28833 Assistant Douglas County Attorney Legal Notice No.: 934737 irst Publication: February 7, 2019 ast Publication: February 7, 2019 ublisher: Douglas County News-Press

Have you seen how Classifieds can work for you?

Attorney for Department: John Thirkell, #13865 R. LeeAnn Reigrut, #28833 4400 Castleton Ct. Castle Rock, CO 80109 (303) 814-5326 FAX 303-479-9259 jthirkel@douglas.co.us lreigrut@douglas.co.us CASE NUMBER: 19JV19 DIVISION 7 DEPENDENCY SUMMONS

also known as: 10648 Braselton St Highlands Ranch, CO 80126 (the “Property”)

This summons is being initiated by the Douglas County Department of Human Services through its counsel.

And BEATRICE TORREZ, Maternal Aunt, Special Respondent.

This Summons is initiated pursuant to Rule 2.2 of the Colorado Rules of Juvenile Procedure, Rule 4 of the Colorado Rules of Civil Procedure, and Section 19-3-503, C.R.S. 2018.

Regarding: LOT 229, HIGHLANDS RANCH FILING No. 122-R, County of Douglas, State of Colorado;

Misc. Private Legals

And concerning: MARIA D. TORREZ, D.O.B.: 10/7/1983, Mother to Selena Deciderio and Jessica Gonzalez; Aunt and Legal Guardian of Rosa Torrez; ISMAEL DECIDERIO-CELTO, D.O.B.: 4/23/1987 or 4/23/1986, Father to Selena Deciderio; AARON GONZALEZ, D.O.B.: 7/1/1981, Father to Jessica Gonzalez; ANNA TORREZ, D.O.B.: 9/16/1981, Mother to Rosa Torrez; DANIEL LARA, D.O.B.: 2/7/1979, Father to Rosa Torrez, Respondents,

Public Notice

FIRELIGHT AT HIGHLANDS RANCH HOMEOWNERS, Plaintiff: v. HELEN ALBER et al., Defendant(s)

You have the right to have this matter heard by a district court judge rather than by the magistrate. You may waive that right, and in doing so, you will be bound by the findings and recommendations of the magistrate, subject to review as provided by sec. 19-1-108(5.5), C.R.S. 2018, and subsequently, to the right of appeal as provided by Colorado Appellate Rule 3.4.

Robert Rotherham, Deputy Douglas County, Colorado

District Court, COUNTY OF DOUGLAS, STATE OF COLORADO CIVIL ACTION NO. 2018CV30402 Division/Courtroom # 3 SHERIFF’S SALE NO. 19000038 NOTICE OF SHERIFF'S SALE OF REAL PROPERTY

The News-Press 37

Guardian ad litem to represent your best interests.

TO: ISMAEL DECIDERIO-CELTO, D.O.B.:4/23/1987 OR 4/23/1986 TO THE RESPONDENT NAMED ABOVE: You are hereby notified that a petition has been filed which alleges that the above-named child is dependent or neglected as per the facts set forth in the Dependency and Neglect Petition, a copy of which may be obtained at the office of the Douglas County Attorney’s Office. A Return of Service and Adjudicatory Hearing for Respondent Father, Daniel Lara, have been set for March 4, 2019 at 8:30 a.m. in Division 7, Douglas County District Court, 4000 Justice Way, Castle Rock, Colorado, 80109. Your presence before this court is required to defend against the claims in this petition. IF YOU FAIL TO APPEAR, THE COURT WILL PROCEED IN YOUR ABSENCE, WITHOUT FURTHER NOTICE, TO CONDUCT AN ADJUDICATORY HEARING AND MAY ENTER A JUDGMENT BY DEFAULT THEREBY ADJUDICATING YOUR CHILD AS A DEPENDENT OR NEGLECTED CHILD. You have the right to request a trial by jury at the adjudicatory stage of this petition. You also have the right to legal representation at every stage of the proceedings by counsel of your own choosing, or if you are without sufficient financial means, appointment of counsel by the Court. Termination of your parent-child legal relationship to free your children for adoption is a possible remedy in this proceeding. If that remedy is pursued, you are entitled to a hearing before a Judge. You also have the right, if you are indigent, to have the Court appoint, at no expense to you, one expert witness of your own choosing at any hearing on the termination of your parent-child relationship. If you are a minor, you have the right to the appointment of a Guardian ad litem to represent your best interests.

Public Notice DOUGLAS COUNTY DISTRICT COURT STATE OF COLORADO 4000 Justice Way Castle Rock, CO Douglas County, CO 80109 THE PEOPLE OF THE STATE OF COLORADO In the Interest of: SELENA DECIDERIO, D.O.B.: 7/7/2009; ROSA TORREZ, D.O.B.: 4/3/2002; JESSICA GONZALEZ, D.O.B.: 12/6/2001, Children,

This summons is being initiated by the Douglas

And BEATRICE TORREZ, Maternal Aunt,

Douglas County 2.7.19 * 6