Quantity Surveying Companies in Dubai-Best Quantity Surveyor UAE

DEZIRE

PROJECT CONSULTANT

TASK AND SERVICE

PRE CONTRACT

POST CONTRACT

COST MANAGEMENT & CONTRACT ADMINISTRATION

CLAIM MANAGEMENT & DISPUTE RESOLUTION

VALUE ENGINEERING

THIRD PARTY EVALUATION

HIGHLIGHTS ON DEZIRE SERVICE BUDGET &

BENCHMARKING

W h a t M a k e s Us S t a n d O u t

COST

REPORTING

TENDER

VALUE

EVALUATION

MANAGEMENT

CONTRACT

DISPUTE

ADMINISTRATION

CHANGE

MANAGEMENT

RESOLUTION

THIRD PARTY EVALUATION

PRE CONTRACT • • • • • •

Benchmarking and Budget Estimate and cost planning Consultant & Sub-consultant procurement services Preparation of BOQ & Pre Tender Estimate Tender evaluation and negotiations Tender & Contract Documentations

POST CONTRACT • • • • • •

Safe guard of the project Payment certification Cost Control and Cost Report Change Management Contractual Advise and Guidance Claims Management

• Project Close out

COST MANAGEMENT & CONTRACT ADMINISTRATION • Administrations of PC & PS items.

• Cost controlling, monitoring & periodical Cost Reporting.

• Timely Cost implications to the clients.

• Cash flow forecasting and monitoring.

• Evaluation of Variations & certification of payments.

• Administration of the Contract and contractual advice.

CLAIM MANAGEMENT & DISPUTE RESOLUTION • Verifying the contractual validity of Claims.

• Make sure parties are following the contractual procedure/ compliance.

• Preparation of Engineer’s Review Reports.

• Determination of Delay & Disruption Claims.

• Mitigating Disputes.

• Supportive services to Arbitration and Litigation procedures.

VALUE ENGINEERING • • • • •

Identification of cost over run items.

Brain storming & data gathering.

Value Engineering proposals.

Presentation of VE proposals to Client.

Cost impact adjustments to the Contract due to VE.

THIRD PARTY EVALUATION • • • • •

For Ongoing project For Completed Projects Re-valuations on Engineers certification Re-valuations on Engineers Final accounts Re-valuations on Engineers determinations on EOT & Claims

PRE & POST CONTRATCT COST CONSULTANCY SERVICES METHODOLOGY 1. Stage 1 - Concept Design Stage 1.1.1 Stage 1A - Pre-Concept Prepare estimated construction cost for the project from the area calculations, initial plans & thematic design report to get a preliminary idea of the financial resources that will be required for the project and to provide the Architect with a budget to design within. Feasibility analysis is excluded from our scope.

1.1.2 Stage 1B – Concept Prepare cost estimate for the project from the Concept design drawings. This type of estimate is derived from unit rates for construction and calculation of square meter areas. The estimate will be based on area calculations.

2. Stage 2 - Schematic Design Stage On completion of Scheme Design, prepare a Scheme Design cost estimate. This type of estimate is derived based on approximate quantities and elemental unit rates for the measurable building elements.

3. Stage 3 - Detailed Design Stage On completion of Design Development Stage, prepare a detailed design cost estimate. This type of estimate is derived based on more accurate quantities and item unit rates,.

4. Stage 4 - Tender Documentation 1.4.1 Stage 4A - Tender Documents Prepare tender documents including conditions to tender, contract conditions, bills of quantities /schedules of rates and other portions for each contract package in accordance with their specialties and requirements. Front End documents include preparing the Instructions to Tenderers, the Particular Conditions of Contract, Tender and Appendix and Form of Agreement in line with Client Requirement. This will be on standard format which is FIDIC based.

1.4.2 Stage 4B - Bills of Quantities The BOQ will include all the civil, mechanical and electrical works items including ID Works. The BOQ will be based on Principles of Measurement International as published by the Royal Institution of Chartered Surveyors and adopted to local customs and practice. Loose furniture and OS & E are excluded.

The BOQ will also include Method of Measurement and Rates Clauses, Preliminaries, and a Schedule of Rates. Drawings and Technical Specifications, Schedules etc. shall be prepared by the Lead Consultant for incorporation into the tender documents.

1.4.3 Stage 4C - Pre-tender estimate Prepare pre-tender estimates for tender package in line with the market rate and to check that the packages prepared are in line with their approved budgets. The BOQ will be prepared for Main Works and Provisional Sum item as per the project requirement.

Combine all the following Tender Volume 1 to 4 for tender floating: • Tender Volume 1 – Conditions of Contract • Tender Volume 2 – Specifications • Tender Volume 3 – Preambles and Bills of Quantities • Tender Volume 4 – Drawings 1.4.4 Stage 4D – Pre-Qualification The Consultant shall assist in identifying suitable vendors.

5. Stage 5 - Tender Stage In the tendering stage, we will handle all tender queries related to Conditions of Contract and Bill of Quantities.

1.5.1 Stage 5A - Tender Analysis and Report (for Main Contract) Carry out detailed commercial analysis of 4 to 5 shortlisted bids received through Tender including arithmetical check on the selected lowest tenders, commercial comparison and analysis of the selected tenders, rate analysis, comparison to pre-tender estimate, review and comment on qualifications and deficiencies, comments on omissions in the bids, verification of bonds, our advice, and recommendations. Prepare Post Tender clarification for the negotiated tenderer.

1.5.2 Stage 5B - Contract Documents and LOI Prepare the Letter of Intent/Award based on post-tender negotiations and correspondence. After issuing the Letter of Intent/Award by the Employer, collate all documents and prepare the formal contract documents for signature by the Employer and the Contractor. Drawings, Specifications and all documents other than Conditions of Contract and Bill of Quantities shall be prepared and provided by the Design Consultant.

2. Article A2 - SCOPE OF SERVICES FOR POST-CONTRACT STAGES 2.1 Stage 6 – Post Contract Services The Consultant shall provide qualified and suitable Quantity Surveyors to carry out the Contract Administration in line with the scope set out below.

2.2 Stage 6A - Construction Stage Services 2.2.1 Financial Statements or Cost Reports Prepare financial statements at monthly intervals. The statements shall show all committed and known intended expenses and their comparison with the original budget allowances. Each Statement shall show the financial implication of the latest awarded contracts, issued drawings, architect’s instructions and claims, Adjustment in Provisional Sum, or Prime Cost Items, Allowance for Contingency etc. and reflect the estimated final account figure for the Works.

2.2.2 Tender documents and Evaluation for PS Items Preparation of provisional sum packages, prepare the tender documents for PS items including conditions of contract and bills of quantities in to compiled documents for tender. The scope includes detailed Tender analysis of selected bid and recommendation for bid finalization and awarding the tender.

2.2.3 Monthly Interim Payment Valuations Prepare monthly interim payment valuations in accordance with the progress of work completed as approved by the Architect. Incorporate financial implications due to design changes etc. as appropriate in the payment valuations. Payment valuation includes the evaluation of work done, variation, material at site etc in accordance with the contract 2.2.4 Assessment of Variations and change Management procedure DPC shall develop the change management procedure for the project and maintain the variation log during construction period. During the course of construction, carry out regular assessments of Engineers instructions, re-measurement of provisional quantities and adjustment of Prime Cost Rates etc. in a timely manner and hold negotiations with the Contractors to achieve preliminary agreements regarding the financial effect of the same. The assessed variations shall be discussed and agreed with the Contractors and formalize for the Employer’s/Engineer’s approval.

2.2.5 Contract Administration and Claim Review and recommendation Procurement of Nominated Subcontract Package in coordination with Employer/Design Consultant /Project Manager at, Assist the Engineer for Tender Floating, Tender Evaluation and Preparation of Nomination and Contract documents for Nominated Subcontract Works.

Assist the Engineer in his administration of the Contract and advice on the Employer’s rights and obligations under the contract, including that in respect of the construction progress, quality, cost and other subjects.

Assist the Engineer/Employer to handle claims submitted by Contractors. Analysis the claims in terms of Cost and assist the Engineer to prepare counter-claims complete with arguments and calculations, where appropriate in coordination with Engineer Analysis the contractual reasons, method of calculation for the claims submitted and assist in the negotiations between the Employer and the Contractor to arrive at an amicable agreement.

2.3 Stage 6B - Final Account Stage Services

2.3.1 Statement at completion/ Final Statement When the Works are practically completed, prepare a draft final account based on the Construction Drawings, Engineers Instructions, Claims, Inspection Reports and other relevant documents. Within circumstances under control of the Quantity Surveyor, the Statement at completion shall be completed within the time prescribed in contract. Dezire shall check the Contractor’s Draft Statement at Completion and Draft Final Statement, in co-ordination with the Engineer, make corrections, if any, the Service shall include, but not limited to, the following; a. b. c. d.

DEZIRE shall guide the Contractor about the exact procedures to follow and the format of the Statement at Completion and the Final Statement.

Review the Statement at Completion and Final Statement and ensure its compliance with the Conditions of Contract.

Review the Consultant’s certification.

Submit the Report to the Client with recommendation.

COST CONSULTANCY METHODOLOGY

Methodology of undertaking the Cost Consultancy Services and Management Organization PRE-CONTRACT SERVICES 1.Preparation of initial estimate at concept stage based on data collection and project brief 2.Preparation of estimate at schematic design stage 3.Preparation of draft BOQ at detailed design stage including draft Conditions of Contract (Volume-1 offender documents) 4.Preparation of final BOQ at final design stage including final Conditions of Contract (Volume-1 offender documents) 5.Assisting in compilation of Final Contract Documents with awarded Contract.

POST CONTRACT SERVICES A. In General - Weekly / Monthly Reports 1.Preparation of weekly and monthly progress reports. Dezire Team will coordinate with project site team leaders and will update all the information required for the works related to QS (All other documents related to administration & document controller like updating logs, etc till completion of project).

B. Contract Administration 1. Assisting the Project Control Team &Project Managers to establish the Client requirements.

2. Ensuring all insurances, bonds and guarantees are in line with the requirement of Contract’s terms and Condition.

3. Developing templates and check list to monitor, control and manage the project cost.

4. Identifying commercial risks and value management concept at earliest and analyzing cost 11.Providing input and assistance into regular Monthly Cost Reports; C. Payment and Certification 1. Review of Contractor’s Payment Applications and substantiation in line with Contract requirements.

2. Preparation of Interim Payment Certificates, Statement at Completion and Final Statement.

3. Quantity reconciliation and preparation of projected value of work done under various Contracts.

Methodology of undertaking the Cost Consultancy Services and Management Organization D. Variation / Change Management / Value Engineering 1. Develop Change management / Variation Procedure in line with Contract Forms 2. Verifying the Cost and time proposal submitted by the Contractor in line with Contract 3. Negotiate with Contractor and prepare preliminary cost estimate for the change order and additional works.

4. Recommend to Client for initial approval with necessary supporting documents 5. Analyze all notice of variations and keep variation log of the same.

6. Upon receiving Client’s consent on proposals, issue Engineer’s instruction to Contractor for Work execution.

7. Preparation of Variations with substantiations and submit to Client for Final Approval 8. Preparation of relevant contractual letters as deemed necessary E. Extension Of Time 1. Advise the site Team for the importance of delay Notices and Contractual Implications and make sure that all notifies delays are recorded 2. Preparing Extension of Time claims if any Client/Consultant related finalization items like Design NOCs, Provisional sum items, modifications in designs, unanticipated incidents etc.

4. Review the Contractor’s Claim and discuss with Contractor/Client for amicable settlements 5. Prepare Claim report and recommendation in order to submit to Client for approval.

6. Review the document related to PS/PC items, prepare the reports and submit to Client for approval.

F. Project Close-out 1. Final Accounts preparation and project close-out with all required documentations.

2. Handover the documents to the Document Controllers of Lead Consultants / Clients as instructed.

W h a t Makes Us Stand Out

INNOVATIVE APPROACH - PROJECTS Brain storming

Feasibility & Innovation workshop

Team setting phase:

Development phase:

Continuous Measurement

01. BUDGETING & BENCH MARKING

Concept Estimate Schematic Estimate Detailed Estimate Measuring Tools • Cost Data • Cost Check • Cost Plan • Detailed BOQ Value Engineering Budget 9

BUDGETING & BENCH MARKING

02. TENDERING & TENDER EVALUATION TENDER EVALUATION Evaluation Methodology • Techno Commercial Evaluation • Review of Tenderers Qualification • BOQ Review • Arithmetical check • Rate review • Exclusion / Inclusions & Deviations • Budget Vs Tender Comparison Post tender clarifications Negotiations Contract documentation

12

03. CONTRACT ADMINISTRATION LINE OF COMMUNICATION

PROJECT ADMINISTRATION • Safe guard of the projects • Implementation of Contract administration procedure • Checking and certification of payments • Administration of Provisional Sums & Prime cost rate items • Assessment of all Variations • Review of Notices / Claim • Determination of Extension of Time • Administrate project close out

CONTRACT ADMINISTRATION Administration of PS/ PC items • • • •

Tender Documents Tender Evaluation Negotiations and PTC Nomination

Determination of Extension of Time • Implement the delay claim procedure and process as per COC. • Review the Contractual validity of the Claim • Reviewing the contractual procedures have been compliance by the Parties (The Contractor, the Employer and the Engineer) • Reviewing analysis of cause and effects for delay events • Analyze the excusable and no excusable delay the project; • Identify the delay caused and the contractual mitigation by the contractor with the help of planner • Determination of EOT

04. CHANGE MANAGEMENT Change Management System which includes early warning system of cost and time over-run consisting of the following: Identifying the sources of changes (Issue of drawings for implementation, answers to RFIs, changes of material specification, change of sequence of works, Engineer’s Instructions, Client or Legislative Changes etc.,); Prepare Request for Approvals (RFA) including approximate estimating of the changes;

Obtaining Client’s approval for increase / decrease of cost and / or time implications.

If the Client’s approval is obtained, proceed with the change. Adjustments to the Contract Sum, Time for Completion and modification to the Contract are to be made accordingly by issuing a Variation Order

34

05. COST REPORTING Monthly Cost Reports prepared by Dezire Project Consultant regularly update the Clients of the following: • Changes to the Contract Sum, • Cost and time impacts of the variations, • Financial status of the project in the reporting month, • Monitoring the progress of the project and time impact due to changes, • Status of the variations, claims and anticipated variations and claims.

• Cash flow forecasting

06. VALUE ENGINEERING

Systematic Value Engineering carried out at Dubai Canal Mixed use development

Our Team

ORGANISATIONAL CHART

SINIMOL NOUSHAD

B.Tech, MBA, FRICS, FAIQS, SSC-ICMS, MIS, CIIQS

CEO DEZIRE Mrs. Sinimol Noushad, is the founder and CEO of DEZIRE Project Consultant and DIA Interiors. Her journey started as Quantity Surveyor to the Commercial Manager through over years till she created DEZIRE Project Consultant, a globally recognized consultant and has achieved pinnacle of success. She was awarded SGA Property Consultancy ‘Woman in Construction Award’ organized by the Australian Institute of Quantity Surveyors in 2013 and short listed as the Finalist for “Woman in Construction Forum Award “by Big 5 Events in Dubai 2019. She has proven her leadership skills during pandemic by articulate a bold and flexible vision, cultivate a culture of innovation, and lead change with empathy and integrity. As the RICS National Board Member & IIQS Chairperson, she promoted the importance of Quantity Surveying Profession in the construction industry in UAE and India among next generation.

ACHIEVEMENTS National board Member, RICS –UAE Chapter Standard setting Committee Member of International Construction Measurements Standards (SSC-ICMS) set out by RICS UAE Chair Person and Magazine Chief Editor of Indian Institute of Quantity Surveyors (IIQS).

Final Nominees for “Woman in Construction Forum Award “by Construction Summit organized by Big 5 Events and Dubai Quality Group” in 2019 Fellow of Royal Institute of Chartered Surveyors (FRICS) Fellow of Australian Institute of Quantity Surveyors (FAIQS) Member of Indian Institute of Surveyors (MIS).

An experienced APC Chair, Assessor, Councilor and Mentor in RICS -Dubai APC Chapter "Young Assessor Commitment Award" In 2011 from RICS. Final Nominees for “SGA Property Consultancy Woman in Construction Award “by Australian institute of Quantity Surveyors” in 2013 Contract & Quantity Surveying from College of Estate Management, UK. MBA in Project Management, Must University, California, USA. Civil Engineering from TKM College of Engineering, Kerala, India.

TEAM LEADS

Sr Contracts Manager Niyaz Mohammed. M

Sr Commercial Manager Srinivas Reddy Yaramada

B.Tech, AAECE, ASSOC RICS

B. Tech , IIT

•

• •

B.Tech in Civil Engineering from Indian Institute of Technology Bombay (IIT Bombay 2003 batch, Ranked #1 University in India Attended workshop on FIDIC contracts conducted by Edward Corbett Pursuing Certified Professional Contracts Manager (CPCM) certification from NCMA, USA

• Year of Experience - 18

• •

•

•

Dubai Municipality approved Quantity Surveyor Certificate course on “Value Engineering in Construction Projects" by Society of Engineers Certificate course on “Contract Administration and “Sound Contract Administration“ Cost Engineering for the CCE examination conducted by AACE, USA. Member of AACE USA(Membership ID - 56838) & Society of Engineers, UAE. (Membership ID -14028)

• Year of Experience - 22

Technical & Admin Manager Nina Balaguru Soman B. Sc Electrical

• • • • •

• MBA in Operations Management B. Sc (Engg) Electrical & Electronics • Engineering Member If AIESCB and Vice President • of the Board Distribution board director in KSEBL and CEO of Uralinkal Attended administrative training in IIM Ahmedabad and Bangalore

Finance and HR Manager Nisha Amith

Accounts Manager Jamaludeen Jana B. Com Degree

B. Sc Electrical MBA in Operations Management B. Tech in Electrical & Electronics Engineering

•

•

Experience : 18 years • •

• Year of Experience - 34 •

B.Com (3 years Degree GPA 3/4) from University of Madras, D.A.P ( 1 year Advance Diploma in Database Application Programming GPA 3/4 Financial Modelling scored 78% HSC 1988 Commerce, Accountancy, Business & Corporate Finance, GPA 3/4.

Currently Pursuing CMA Certified management Accountant

• Year of Experience - 26

TEAM LEADS

Sr. Claim Specialist Palitha Gamage

LLM,Pg Dip in Arb,FRICS,MCIArb,AIQS

• •

• • • • •

Master of Construction Law & Arbitration Post Graduate Diploma in Arbitration Direct Membership Professional Examination of the Royal Institution of Charted Surveyors Fellow of RICS Member of Chartered Institute of Arbitrators Fellow of AIQS Associate of Institute of QS, Sri Lan Year of Experience - 38

Managing Quantity Surveyor Abdul Nazer

Contract Administrator

BTech, Bsc QS, AMIE, ASSOC RICS

BSc QS, MRICS, MAIQS, MISLQS

• B. Tech in Civil Engineering, •

•

B. Sc QS from College of Estate Management (UK) in 2009 Diploma in Associate Member of the Institution of Engineers (AMIE), India Approved Quantity Surveyor by Dubai & Abudhabi Municipality RICS Student Member

•

Year of Experience - 36

• •

Cost Manager Ebison Gomez

Duminda Mihran • • •

•

Bachelor Degree in Quantity Surveying Chartered Member of Royal Institution of Chartered Surveyors, (MRICS) Member of Australian Institute of Quantity Surveyors, (MAIQS) Graduate Member of Institute of Quantity Surveyors Sri Lanka Year of Experience - 10

Planning Manager Ratheesh Ramakrishnan BTech Mech, PMP, Prima P6

Dip. Civil Eng., Dip. QS, MIIQS, CCS

• • •

• •

Diploma in Civil Engineering Member of Indian Institute of Quantity Surveyors (IIQS) Certified professional in CCS Year of Experience - 13

•

•

•

Bachelor of Technology (B. Tech), Mechanical Engineering Certification course in Project Planning Software’s Primavera P6,P5,P3 and Microsoft Project (2005) Project Management Professional (PMP)® Program from Cambridge Educational Institute, Sharjah-UAE(2009) Year of Experience - 16

OPERATIONAL TEAM LEADS

• •

•

• • •

Cost Manager SUJITH SURENDRAN Diploma in Civil Engineering E-Tender Practise & DM Training Experience : 14 years

SHREEHARI KEMBHAVI BSc (Hons) in Quantity Surveying Diploma in Civil Engineering Experience : 15 years

Managing Quantity Surveyor DEEPU SAJEEV MBA in Project Management B.Tech Civil Engineering E-Tender practise & DM training Experience : 17 years

• • • •

• • • •

Project Quantity Surveyor SATEESH BABU GUNDA Master Degree in Quantity Surveying B. Tech Civil Engineering Diploma in Civil Engineering Experience : 17 years

ISHANI KOTAKARAYAN (MRICS) • • • •

BSc (Hons) in Quantity Surveying MSC in Commercial Management Diploma in Quantity Surveying Experience : 11 Years

• • •

RAJESH THOPPIL B-Tech in Civil Engineering Diploma in Civil Engineering Experience : 21 years

• • •

Project Quantity Surveyor SURANGA BSc (Hons) in Quantity Surveying and Construction Management National Diploma in Quantity Surveying and Building Economics Experience : 19 years

• •

JAIME CAMPOS Bachelor in Civil Engineering Experience : 21 years

DPC-Pre-Qualification

2.3 Staff List and Associated Grading Number of years experience as Cost-Consultant: UAE

INDIA

8 years

7 years

Total number of Key Management and Technical Professionals: Management:

Technical:

1

No. of Staff: Total:

Administration:

45

6

52

Dubai

Other UAE areas

Gulf & ME

Other (India)

Director

1

x

x

0

Professional / Technical Staff

35

x

x

10

Admin / Support Staff

4

x

x

2

Total Staff

40

x

x

12

No. of Staff

DEZIRE PROJECT CONSULTANT

DPC-Pre-Qualification

2.3 Staff List and Associated Grading Key Managerial and Technical Personnel in UAE and indicated their qualifications and number of years experience: Position

Managing Director

Contract & Commercial Manager, Claim Specialist

Sr. Commercial Manager

Managing Quantity Surveyor

Sr. Contracts Manager

Sr. Quantity Surveyor

Sr. Quantity Surveyor

Name

Professional Qualifications

• B. Tech in Civil Engineering • MBA in Project Management Sinimol Noushad • Contract and QS from College of Estate B. Tech, MBA, Management – UK FAIQS, FRICS, • National Board Member-RICS, UAE MIS, SSC-ICMS, • Standard Setting Committee for International CIIQS Construction Measurement Standards, California - SSC-ICMS • Master of Construction Law & Arbitration Palitha Premasiri • Post Graduate Diploma in Arbitration Gamage • Direct Membership Professional Examination LLM, Pg. Dip. in of the Royal Institution of Charted Surveyors Arb, FRICS, • Fellow of RICS MCIArb, AIQS (SL), • Member of Chartered Institute of Arbitrators FAIQS • Fellow of AIQS • Associate of Institute of QS, Sri Lanka • B. Tech in Civil Engineering from Indian Institute of Technology Bombay (IIT Bombay 2003 batch, Ranked #1 University in India Srinivas Yaramada • Attended workshop on FIDIC contracts B.Tech, IIT conducted by Edward Corbett • Pursuing Certified Professional Contracts Manager (CPCM) certification from NCMA, USA • B. Tech Civil Engineering Abdul Nazer • B. Sc Quantity Surveying (UK) BTech, BscQS, AMIE, ASSOC • Diploma in Associate Member of the Institution RICS of Engineers (AMIE), India (DM Approved QS) • RICS Student • B. Tech Civil Engineering Niyaz Mohammed • Pursuing RICS - APC Candidate No. 6763669 (DM Approved • Dubai Municipality approved Quantity QS) Surveyor and Civil Engineer • Member of AACE (Association for Advancement of Cost Engineering) • Member of Society of Engineers, UAE • Master’s Degree in Quantity Surveying Sateesh Babu Gunda • Bachelor of Civil Engineering Msc, B.Sc. (Hons) • Diploma in Civil Engineering • Bachelor’s Degree in quantity surveying Duminda Mihiran • Chartered Member of Royal Institution of Gunarathne, Chartered Surveyors, (MRICS) BscQS, MRICS, • Member of Australian Institute of Quantity MAIQS, MISLQS Surveyors, (MAIQS) (DM Approved • Graduate Member of Institute of Quantity QS) Surveyors Sri Lanka

DEZIRE PROJECT CONSULTANT

Exp

22 yrs.

38 yrs.

18 yrs.

36 yrs

22 yrs

20 yrs

11 yrs

DPC-Pre-Qualification

Position

Name

Professional Qualifications

Exp

Technical & Admin Manager

Nina Balaguru Soman

• MBA in Operations Management • B. Sc (Engg) Electrical & Electronics Engineering

34 yrs

Sr. Quantity Surveyor

Jaime Campos B Tech Civil

• Bachelor of Science in Civil Engineering

22 yrs

Project Planner

Rajesh Thoppil B Tech, Diploma

Sr. Quantity Surveyor

Suranga Premaratna BSc. Diploma in QS

Finance and HR Manager

Nisha Amith

Sr. Quantity Surveyor Sr. Quantity Surveyor

Bijulal Rajan Baby B Tech, Diploma, MIIQS (DM Approved QS) Sangeeta Balasubramanian Diploma

• Diploma in Civil Engineering • B. Tech in Civil Engineering • BSc (Hons) in Quantity Surveying and Construction Management • National Diploma in Quantity Surveying and Building Economics • National Certificate of Technology in Quantity Surveying • MBA in Operations Management • B. Tech in Electrical & Electronics Engineering

21 yrs

19 yrs

18 yrs

• B. Tech in Civil Engineering • Diploma in Civil Engineering

17 yrs

• Diploma in Civil Engineering

17 yrs

17 yrs

Managing Quantity Surveyor

Deepu Sajeev

• MBA in Project Management • B. Tech Civil Engineering • E-Tender practice & DM Training

Planning Manager

Ratheesh Ramakrishnan, B Tech Mech, PMP

• B. Tech Mechanical Engineering • Project Management Professional

16 yrs

Sr. MEP Quantity Surveyor

Sunil D. Navalgund B Tech Mechanical

• Bachelor of Engineering, Major in Mechanical

15 yrs

Sr. Quantity Surveyor

Shreehari Kembhavi B Tech Civil

• B. Tech in Civil Engineering • Diploma in Civil Engineering

15 yrs

Cost Manager Sr. QS/ Estimator

Sujith Surendran Diploma

• Diploma in Civil Engineering • E-Tender practice & DM Training

14 yrs

Cost Manager Sr. QS/ Estimator

Gregorious Ebison Gomez, Diploma Civil Eng., Dip. MIIQS, CCS

• Diploma in Civil Engineering • Member of Indian Institute of Quantity Surveyors, (IIQS) • Certified Professional in CCS

14 yrs

Sr. QS/ Estimator

Mohamed Nifras Msc, B.Sc. (Hons)

• B.Sc. (Hons) in Quantity Surveyor and • Msc Construction Management

12 yrs

Quantity Surveyor

Ishani Kotakarayan (MRICS)

• BSc (Hons) in Quantity Surveying • MSC in Commercial Management • Diploma in Quantity Surveying

11 yrs

MEP Quantity Surveyor

Jincy Mathew B.E Electrical Engg

• B.E Electrical Engineering • Trained for E-Tender and Analysis

10 yrs

DEZIRE PROJECT CONSULTANT

DPC-Pre-Qualification

Position

Name

Quantity Surveyor

Juzail Jasooly B Tech Civil

Quantity Surveyor

Professional Qualifications

Exp

• National Diploma in Technology – Quantity • BSc in Quantity Surveying

7 yrs

Sreeraj Sivarajan B Tech Civil Engg

• Bachelor’s Degree in civil engineering • Certificate in Quantity Surveying

7 yrs

Project QS

Mohammed Ismail B Tech Civil

• B. Tech in Civil Engineering

7 yrs

Quantity Surveyor

Gigy Thomas B Tech Civil

• B. Tech Civil Engineering • Trained for E-Tender and Analysis

7 yrs

Quantity Surveyor

Anas Basheer B Tech Civil Engg

• Bachelor’s in Civil Engineering

7 yrs

Quantity Surveyor

Roshen P. Raju B Tech Civil Engg

• Bachelor of Technology in Civil Engineering • Pursuing Master of Business Administration in International Business • Certificate in QA/QC Civil

6 yrs

Quantity Surveyor Quantity Surveyor

Husna Paruvingal B Tech Civil Kosala Premudini Herath

• Bachelor’s in Civil Engineering

6 yrs

• National Certificate in Quantity Survey with Merit pass

5 yrs

Aju Vijayan • Bachelor’s Degree in Mechanical Engineering B.E Electrical Engg

5 yrs

MEP Quantity Surveyor Administrative Assistant

Michelle Mae Santos

PRO

Mohammed Raeez

Associate Associate Quantity Surveyor Quantity Surveyor/ Estimator Quantity Surveyor Quantity Surveyor Quantity Surveyor Jr. Quantity Surveyor Jr. Quantity Surveyor Jr. Quantity Surveyor Driver

• Certificate in Computer Secretary

11 yrs

• Master of Commerce

10 yrs

Lalitha Alexander

• B. Tech in Civil Engineering • CMA

22 yrs

Fatima Zaphyne

• Bachelor’s Degree in business management

28 yrs

• B. Tech in Civil Engineering • Diploma in Civil Engineering

15 yrs

• Diploma in Civil Engineering • Certificate Course in Quantity Survey

14 yrs

John Jenin J B Tech Civil Engg, Diploma Vishnu Das B Diploma, Certificate in QS

• B. Tech in Electrical Engineering

5yrs

Amal A. Sunil

• B. Tech in Civil Engineering

5 yrs

Gireesh G

• B. Tech in Civil Engineering

4 yrs

Aromal SS

• B. Tech in Civil Engineering

4 yrs

ThasneemShaheer

• B. Tech in Civil Engineering

3yrs

Harikrishnan. K

• B. Tech in Civil Engineering

3 yrs

Alen David

• B. Tech in Civil Engineering

5 yrs

Shahad

DEZIRE PROJECT CONSULTANT

Curriculum Vitae 2021

Name

:

Niyaz Mohammed. M

Profession

:

Sr. Contract Manager

Year of Experience

:

22 Years

Qualification

:

B. Tech in Civil Engineering, 1997 T.K.M. College of Engineering, University of Kerala, India

Professional Memberships:

DM APPROVAL

:

Professional & Computer Skills

:

Professional Experience:

Pursuing RICS – APC Candidate No. 6763669 Member of AACE Member of Society of Engineers Approved Quantity Surveyor and Civil Engineer by Dubai Municipality

• • • • •

Knowledge of FIDIC, POMI and CESMM3.

Strong leadership and project management skills.

Confidence to meet any challenge.

High negotiation, communication and organization skills.

AutoCAD & 3D Home Architect.

Primavera.

M/s Dezire Project Consultant, Dubai, U.A.E. Senior Contract Manager June 2021 – Present Duties & Responsibilities  Preparation of Engineer’s Review Reports to Contractor’s Extension of Time & Prolongation Cost Claims complying with DM procedure.  Evaluation of Contractor’s claim for Employer’s Acceleration  Involving in contractual and commercial correspondences and keep recording of correspondences.  Administration of Provisional Sums in the Contract including Preparation of Tender documents, involving in Tendering procedure & Preparation of Tender Analysis Reports to select Nominated Subcontractors.  Following Change Management System of the project including variation notifications, cost estimates, variation instruction & approved value for variation.  Preparation of monthly & quarterly Cost Reports including Revised Remeasurement cost, Variations, Claims and Contingencies.

M/s Project Management Group PMG, Dubai, U.A.E. Commercial Manager July 2013 – 2021

Duties & Responsibilities;  Review and approval of monthly payment certificates of Consultants and Contractors.  Value Engineering & Contracts Administration for different types of projects.  Review and approval of Contract documents submitted by Consultant and Main Contractors  Attending meetings with Consultants and Contractors as Client representative.  Review and approval of Claims and Variations.  Advice Client regarding legal and Contractual issues related to the Project.

Niyaz Mohammed. M

Page 1

Curriculum Vitae 2021

Major Projects: • Mirdif Hills Development, Dubai Investment and Real Estate Co. (DIRC), Project Value, AED1.50 Billion • Showrooms, Offices and Workshops, M/s. Al Habtoor Motors(Mitsubishi Showrooms) • Danzas Warehouses, M/s. Al Tayer Group M/s System Construct LLC, Dubai, U.A.E. Senior Quantity Surveyor Sep 2010 to June 2013

Duties & Responsibilities;  Preparation of monthly interim payment certificate.  Evaluation of Variations and maintaining variation log sheet.  Review of sub-contractor payments.  Assist the Project Managers in the contractual issues.

Major Projects: • Four schools under Abu Dhabi Future Schools Program , Abu Dhabi Educational Council, (ADEC) Abu Dhabi, UAE, AED 372.00 Million M/s Al Ajmi Engineering Consultants, Dubai, U.A.E. Senior Contract Engineer January 2007 to September 2010

Duties & Responsibilities;  Develop and manage efficient tender and effective contractual process.  Manage the post contract administration of awarded contracts, review and approval of interim certificates, monitor and control project cost.  Claims negotiations and finalization of variation orders.  Value engineering.  Ensure all contractual certificates and guarantees by Contractor are in place.  Provide leadership and commercial facilitation to contract engineers & project managers.  Review of tender and contract documents as per FIDIC, POMI etc.  Tender evaluation, negotiations and finalization of contract.

M/s KEO International Consultant, Dubai, U.A.E. Quantity Surveyor June 2005 to January 2007

Duties & Responsibilities;  Evaluation of interim payment certificates as per conditions of contract.  Evaluation and analysis of prices and rates for variation review.  Review and evaluate contractors claim and variations.  Finalization of variation and preparation of final account.  Maintain technical records for all documents like engineers instructions, correspondence, drawings, all variations, payment certificates, sub contract works etc.  Preparing Value Engineering analysis where the bid amounts has exceeded the budgeted allowances for the nominated packages.

Major Project:  PALM JUMEIRAH Project of NAKHEEL - comprising of more than 1650 super luxurious villas like Signature Homes, Garden Homes & Canal Cove Villas and 60 sub stations. These villas having four to seven bedrooms. Three main contractors and several sub-contractors.

Niyaz Mohammed. M

Page 2

Curriculum Vitae 2021

M/s International Engineering Consultants, RAK, U.A.E. Quantity Surveyor// Projects Engineer Nov 2003 to May 2005

Major Project: Project Engineer of G+M+2 storey building for National Bank of Abu DhabiRAK Branch. G+M for bank and the rest are flats. This project is with Strong Rooms, Curtain Wall, Panoramic Lift, False Ceiling, Glass Partition and having various services like Structural Cabling, CCTV, Security System, Fire Fighting, Fire Alarm, Split, Duct & Central A/c systems etc.

Quantity Surveying, Valuation and Tender preparation for Masafi HospitalFujairah, Multi Storied Buildings, Private Villas, Mosques etc. in different parts of Ras Al Khaimah.

M/s Nasser S Al Hajri Corporation, Yanbu, KSA Quantity Surveyor// Projects Engineer April 2002 to May 2003

Duties & Responsibilities;  Prepared all contract documents for sub contract works.  Independently in charge of the material submittal and its approval under Purchase Department.  Estimation of all materials is taken subjected to this project including housing and infrastructure works.  Data are collected from different manufacturers/ suppliers and suitable material is selected and is submitted to the consultant/ Royal Commission for approval.  After getting the approval, sub contract is prepared after price negotiations and purchase order is issued.

Major Project: Yanpet Housing Project, Yanbu, KSA. Project consists of Construction of 200 luxuriousvillas for Yanbu Petrochemicals Ltd (YANPET). Quantity of all materials taken especially finishing items like ceramic tiles, floor carpet, curtains for doors, windows and toilets. 92 patterns of ceramic tiles were selected by the 200 villa owners and its quantity was taken accordingly.

Quantities of steel and concrete were taken separately for grade slab, columns, beams, slabs etc. Prepared comparative statement between the quantities as per BOQ and actual consumption at the site and its cost implications.

M/s Charangattu Engineering, Kochi, Kerala, India Projects Engineer November 1997 to December 2001

Worked as Project Engineer from November 1997 to December 2001 under Civil Construction Division of Charangattu Engineering, one of the leading contractors of Indian Railways and Kerala State PWD(Public Works Department.)

Duties & Responsibilities;  Execution of Piling works including precast and cast insitu piles  Prestressed concrete structures for bridges and culverts  Preparation of work chart for tenders  Managing supervisors in the execution of work Niyaz Mohammed. M

Page 3

Curriculum Vitae 2021

Name

:

SRINIVAS YARAMADA

Profession

:

Sr. Commercial Manager

Year of Experience

:

18 years

Qualification

:

B.Tech in Civil Engineering Indian Institute of Technology Bombay (IIT Bombay 2003 batch, www.iitb.ac.in). Ranked #1 university in India.

• • •

Professional & Computer Skills :

Professional Experience:

Professional Experience:

SRINIVAS YARAMADA

Attended workshop on FIDIC contracts – A Practical Guide to Understanding and using the FIDIC conditions of contract 1999 conducted by Edward Corbett Completed Sound Contract administration training programme conducted by Dr. Sam Pursuing Certified Professional Contracts Manager (CPCM) certification from NCMA, USA

• • • • • • • • • • • •

Procurement Contracts management Quantity Surveying Claims management Supplier Relationship Management Budgeting Reports & Dashboard Estimation Negotiations Cost control Performance Metrics Category management

•

A Commercial Manager in Nakheel PJSC. 15 years of experience in Nakheel PJSC (www.nakheel.com), a leading real estate development and property management company based in Dubai as Quantity Surveyor, Contracts engineer and Commercial Manager. (2006 till date)

•

3 years of experience in leading constructions companies Al Basti & Muktha (www.abmdubai.com) as Estimation Engineer and Larsen &

•

Toubro (www.lntecc.com) in Dubai as Senior Contracts Engineer.

(2003 to 2006)

Procurement and Tender Process Management  Managed the complete source to contract (S2C) cycle including procurement planning, tendering, negotiations, award and the execution of the contract.  Handled procurement for a diverse portfolio of real estate development projects including construction of residential, retail, high rise, infrastructure and design consultancy services. Handled 50+ tenders with an award value of AED 5+ billion.

Page 1

Curriculum Vitae 2021

 Managed the procurement for facilities, property and community management business verticals for a portfolio of 10 master communities with an annual budget of AED 300+ million.  Managed the procurement for corporate services including IT, finance, marketing, HR and general administration with an annual budget of AED 80+ million.  Consistently delivered 15% savings through negotiations, value engineering and strategic sourcing.  Assisted the development team in preparation of budgets for real estate developments using estate master. Assisted the community management team in preparing the budget for facilities management, master community and jointly owned properties as per RERA approved formats.

Contracts Management  Provided post contract quantity surveying and contract management services to project management division for large construction projects and facilities management business.  Reviewed the variations, extension of time claims, final account settlement, termination and suspension claims with the objective of minimizing the risk of disputes while working within the framework of the contract.  Experience in working with FIDIC based form of contracts for construction projects and in-house form of contracts for facilities, property, and community management.

Claims Management  Managed the complete claims process for large value construction contracts from interim claim notification stage until resolution of the claim including  Review of interim claim reports prepared by project consultant  Appoint external delay analysis consultants where required. Manage the external claims consultant and ensure deliverables are of required quality.  Prepare comprehensive management reports with various scenarios.

Negotiation, drafting and execution of the final settlement agreement.

Supplier Relationship Management  Initiated and setup in-house online vendor registration system in collaboration with IT department resulting in completely automated and paperless process for vendor registration.  Experience in supplier pre-qualification, supplier segmentation, supplier risk and performance evaluation.  Handled a supplier network of 500+ companies including leading construction contractors, design consultants, facilities management companies, IT and marketing companies among others.  Setup Taxonomy consisting of 400+ categories of commodities covering the entire portfolio of a real estate developer including construction, facilities management and corporate services.

SRINIVAS YARAMADA

Estimation and Cost Control  Managed the entire bidding cycle for a contracting company from enquiry stage through to contract realization including reviewing scope of work, assessing site conditions, quantity take-off, cost estimates, tender submission and post tender negotiations.  Prepared budget for awarded contracts and monitored actual cost against budget.

Page 2

Curriculum Vitae 2021

 Some of the bids won include Knowledge Village Phase 2, Gold & Diamond Park, Golf Towers, Old Town at Downtown Dubai with contract values ranging from AED 30million to AED 500million+.

Policies, Procedures and Transformation  Led the digital transformation of procurement and contracts management processes in collaboration with IT department. Evaluated P2P systems, drafted high-level functional requirements and oversaw the implementation of Oracle procurement suite of products. Evaluated products for supplier relationship management (SRM) and contract life cycle management (CLM).  Initiated and setup workflows in collaboration with IT department to automate various internal processes resulting in reduction of process cycles by up to 70%.  Nominated as Project Manager for Procurement & Contracts transformation project (led by Big4 consulting firm) to oversee delivery of the objectives of the project. Reviewed the deliverables for quality and conducted periodic meetings to present the deliverables to the senior leadership and department heads. Conducted change management sessions with all stakeholders to drive the adoption new policies and procedures resulting from transformation.  Nominated as Business Partner for Nakheel Communities Management to provide expert procurement and contracts advice to the business. Helped the business in integrating the Urbanise facilities and strata management software to Oracle procurement suite.  Initiated and setup procurement procedures including a flow chart of processes, set-up standard tender suites in consultation with legal department and developed standard form/templates for day to day tasks.  Drafted Key Performance Objectives and Rating Criteria for all roles across the procurement and contracts department.  Drafted roles and responsibilities of Tender Opening Committee and served in the capacity of member of tender committee.  Drafted the delegation of authority and internal controls for procurement and contracts department resulting in smooth business operations.

Special Projects  Conceptualized the cost model and drafted the process and contract template for providing dewatering services to Nakheel’s third party developers resulting in a revenue of over AED 67 million over 5 years.  Drafted and implemented the process and agreement template for sale and auction of surplus and scrap material. This process was implemented across all business units of Nakheel resulting in sale of material of over 113 million in 125 transactions over a period of 5 years.

SRINIVAS YARAMADA

Page 3

Curriculum Vitae

Name

:

SURANGA PREMARATNA BSc. (Hons) Quantity Surveyor

Profession

:

Contract Administrator / Senior Quantity Surveyor

Year of experience

:

17 years

Qualification

:

2021

BSc (Hons) in Quantity Surveying and Construction Management Sheffield Hallam University, UK, 2013 National Diploma in Quantity Surveying and Building Economics International College of Business & Technology together with the Edexcel, UK National Certificate of Technology in Quantity Surveying Technical College, Aruppola, Kandy, Sri Lanka, 2002

Courses & Trainings

Key Areas Experience:

SURANGA PREMARATNA

:

 Conducted a research in the form of a dissertation on “The types of reports are to be maintained in delay claims by the Contractors as per the FIDIC Conditions of Contract” as a part of the academic requirements for the degree programme.  Civil Engineering Standard Method of Measurement (CESMM3/4), London  Standard Method of Measurement of Building works (SMM7)  FIDIC Forms Condition of Contract  DM & DEWA Standards/ Specifications  TECOM Condition of Contracts, Dubai Properties Conditions of Contract.  Dubai Holdings Conditions of Contracts implemented in year 2017  Sri Lankan Standard Method of Measurement (SLS 573), SL; Standard Bidding Document – Procurement of works, SL and “ICTAD Condition of Contract”, Sri Lanka.

The experience gained is diversified across multi-stakeholder environment of client, consultant, contractor organizations with the key strengths and all level of extensive competence such as but not limited to: • Manage all pre & post contract administration procedures for contractors and consultants.

• Manage all in-house project/ Client’s direct project (without consultant) pre & post contract administration procedures for contractors throughout the project from starting to handing over.

• Track variations/ claims and recommend corrective actions to minimize such variations and monitor the overall budget.

• Manage/ resolve disputes by settlements, negotiation, arbitration etc, in collaboration with legal department.

• Prepare management reports (such as project accruals, progress report, cash flows) to provide management information on timely manner in order for to take corrective actions.

• Evaluate and qualify the consultants/ contractors/suppliers pre-qualifications and engage in development of procedures.

• Sound interpretation of contract practices and provide input for implementation of standard contractual practices and procedures.

• Thoroughly involved in development of new online /oracle systems for payment certifications/ variations/ cash flows/ pre-qualification.

Professional Experience

:

Curriculum Vitae

2021

TECOM Investments, Dubai, UAE. Contract Administrator August 2013 to June 2018 Duties & Responsibilities • Dealing with all contractual and commercial aspects of all assigned projects from pre-contract stage to handing over stage • Review of tender documents/ contract documents, preparation of request for proposals for consultants, tender evaluations/ preparation of consultancy agreements.

• Payment certification for contractors/ consultants, evaluation and negotiation of variations; review and evaluation of claims; cost saving variations; budgeting, cash flow forecasting and cost reporting.

• Attending meetings with contractors and consultants; preparation of RTPs, de-scope/ suspension/ termination letters; preparation, review, recommendation and approval of various consultant and contract agreements and letter of acceptance.

• Offering various contract administration advice for the ongoing issues, involved in implementation of new online /oracle systems for payment certifications/ variations/ cash flows/ pre-qualification.

• Preparing of tender documents/ contract documents, tender evaluations/ preparation of contract agreements.

• Review and certify payment certificate for contractors, evaluation and negotiation of variations; review and evaluation of claims; prepare of nomination letters, prepare of cost saving variations; budgeting, cash flow forecasting and cost reporting, attending meetings with contractors, preparation, review, certify and approval of various contract agreements and letter of acceptance for in-house project/ Client’s direct project (without consultant) Major Projects: • Makateb Office Building for IMPZ at Plot no. MB-16 & 20. Approximate Project Value AED 200 Million, • Office Building (3B+G+3) on Plot No. A009-004 at TECOM Site A - Pilling works and Main Building Works (3B+G+3). Approximate Project Value AED 80 Million, • Office Building (G+6) on Plot No A004-016 at TECOM Site A - Main Building Works. Approximate Project Value AED 280 Million, • Dubai Studio City P-088 - Roads & Infrastructure Phase 1, Stage 2.

Approximate Project Value AED 110 Million, • TECOM Roads Networks Improvements - Infrastructure Works. Approximate Project Value AED 100 Million, • Various Improvements for TECOM Sites - Roads, Infrastructure and Landscaping Design & Construction Services. Approximate Project Value AED 25 Million, • Landscaping at TECOM Site A – Landscaping works. Approximate Project Value AED 60 Million approximately, • Landscaping at TECOM Site B & C – Landscaping works. Approximate Project Value AED 40 Million, • Pepsico Offices and Laboratories at Dubiotech Lab Building, second floor Fit-out works - Approximate Project Value AED 2.5, • GEMALTO Office at DSC Tower Building in Dubai Studio City - Fit-out works - Approximate Project Value AED 1.5 Million, • Dubai Internet City Lake’s Rehabilitation - Liner Replacement and Cleaning Works. Approximate Project Value AED 3.5 Million, SURANGA PREMARATNA

• •

Curriculum Vitae

2021

Various landscaping and Fit-out works, Various Master planning project (DSC, D3)

N. E. Azzam & Partners (Chartered Quantity Surveyors- Cost Consultants) Project Senior Quantity Surveyor March 2006 to August 2013 Duties & Responsibilities • Quantity Surveyor dealing with preparation of bill of quantities; tender evaluation; compilation of tender documents and contract documents; cost planning, estimating and reporting; value engineering.

• Preparation of rate analysis; payment certification, evaluation of variations; evaluation of claims.

• Preparation of client supplied material reconciliation reports; cost reporting; attending meetings with clients, contractors and sub-contractors.

Major Projects: • Commercial Office @ DSC- 1 Basement + four 5 story & one 12 story office Building. Approximate Project Value AED 275 Million, • Holiday Inn Hotel at knowledge village (DP), • 2B+G+5 Office Building at knowledge village (DP), • Tijara town: Warehouse, Parking, Retail, Residential and Office building.

• Prime Tower: Office tower • International city - Stage 2,3 and 4: Infrastructure • Jebel Ali village: Infrastructure • Khalidiya Palace: Hotel (ID work) • Rak Hilton hotel (ID work) • Large and Small Soundstages • The villa phase 01 J.B. Atthanayake & Company Pte Ltd (Contractor), Kandy, Sri Lanka Project Quantity Surveyor May 2001 to March 2006 Duties & Responsibilities • Duties & Responsibilities: carry out monthly valuations of work in progress, including forecasting of final costs.

• Prepare and monitor project cash flow forecasts. Measure, value, submit and negotiate contract variations. Provide advice to project staff on commercial and contractual matters including reviewing and drafting of correspondence.

• •

Prepare submit and negotiate project final accounts. Preparation of tender document and contract document for sub-contractor. Certification of subcontractor monthly valuations and final accounts.

Ensure that business commercial processes are adhered to at project level.

Assist in preparation and adherence to project purchasing targeting and costing budgets.

Major Projects: • School Extension at Aralaganvila, Sri Lanka. Approximate Project Value USD 20 Million.

• Extension of National Institute of Co-operative Development, Polgolla, Sri Lanka. Approximate Project Value USD 40 Million.

• Building Project in Wagolla, Kandy, Sri Lanka. Approximate Project Value USD 50 Million.

• Various Infrastructure and Roads Networks Improvements.

SURANGA PREMARATNA

Curriculum Vitae 2021

Name

:

GREGORIOUS EBISON GOMEZ

Profession

:

Quantity Surveyor / Estimator

Organization

:

M/s Dezire Project Consultant

Qualification

:

Diploma First Class with Distinction in Civil Engineering Kerala India, April 2007

Year of Experience

:

14 years

Courses

:

Diploma First Class with Distinction in Civil Engineering

Affiliates/ Professional : : : Key areas

Professional Experience:

:

Certification program of CCS (Construction computer software) in Dubai, UAE Certification program of AUTOCAD Certification program of Primavera P3 Having 13 years of experience in construction industry. I have worked in both pre and post contract Quantity surveying service such as Tendering, Preparation of Bill of Quantities, Quantity takeoff, estimation, Value engineering, Negotiation, Contract formation including Post contract services in terms of Payment applications, Cost estimate for variations, Final Accounts preparation and project close-out.  Well experienced in pre-and post-contract cost management on a wide range of Construction Projects for major Clients, Project Management Consultants, Supervision Consultant and Contractors in UAE,  Familiar with FIDIC Conditions of Contract / Dubai Municipality Conditions of Contract for Works of Civil Engineering Construction  Well versed with POMI (Principles of Measurements - International)  Handled projects from Concept Design estimate to Final completion  Handled all Quantity Surveying activities of Pre-contract and Post-Contract works independently for Dubai Municipality Projects M//s Dezire Project Consultant, Dubai, UAE Sr. Quantity Surveyor August 2017 – Present Dezire Project consultant is the specialist consultant in Cost and Quantity Surveying and I am currently working as part of the Cost and QS team, taking responsibility for several schemes at differing stages and working with limited supervision such as prepare or review the tender and contract documents comprising of BOQ, specifications, agreements, forms and other contractual correspondences; evaluate tenders and prepare the evaluation reports; prepare estimates, cost break down.

My responsibilities have been extended to coordinate or lead Pre and Post contract QS team and reporting to CEO.

Duties & Responsibilities- Various Projects  Responsible for cost management services in terms of budgeting, cost estimate, and tender review  Prepare Cost Plan (functional area, unit, and elemental method) for various stages of Construction, such as Concept, Schematic, Interim DD, Detailed Design, GREGORIOUS EBISON GOMEZ Page 1

Curriculum Vitae 2021

 Provide Value Engineering advise to achieve effective time and cost.  Prepare cost analysis report,  Deal with various consultants, and incorporate design development changes on the cost estimate,  Responsibilities include valuation of works executed and preparation of payment application, including Civil & MEP works.  Review Valuation of change orders and quantification of costs related to claims.

M/s Condor Building Contracting Co. LLC, Dubai, UAE Sr. Quantity Surveyor, March 2013 to March 2017 As Senior Quantity Surveyor Job responsibilities  Preparation of Bills (Interim, Statement at discharge & Final Statement).  Identify and calculate all variations and prepare variation reports for management.  Evaluate and recommend valuation of suppliers and sub-contractors' variation claims. Register the variation for main & subcontract for review and recommend all variation submitted by contactor.  Preparation of Payment Application, Prime cost analysis & Provisional sum Adjustments for the Pre final bill. Prepare the rate build up for main contractor variations works and substantiate with the client / consultant.  Final Closing out of the project.  Analyze tenders and make the necessary studies for specifications.  Make technical envelope includes all consultants' requirements.  Getting Certification in Sub contractor Invoice from concerned Project Manager. Evaluate supplier and sub-contractor quotes and prepare quotation comparisons.  Study direct and indirect cost to re-evaluate unit rate for each item.  Cross checking the measurement sheet of sub-contractor.  Checking previous payments made to the sub-contractor.  Preparing the payment certificate based on the payment terms  Co-ordination with consultants, client & sub-contractor. Maintaining a high degree of professional skills& organizational behavior.  Exposure to Pre-contract, bidding and familiar with tender procedures.

Projects Completed • Extension of Rashid Hospital • ADNOC Filling Station at Old Baniyas • Civil Defense Station • G+2 Gems School at RAK • ADNOC Filling Station at Mafraq • 164 Villas for TECOM Investments • ADNOC Linear Stations (6 Nos) • ADNOC Conversion to smart station • G+1 Villa at Pal Jumeirah • Mudon Community Center • ADNOC Filling Station at Sharjah • Ruwais Recreation Center • Al Futtaim Data Center • Bakery for Bake mart at Dubai GREGORIOUS EBISON GOMEZ

- AED 165 million - AED 30 Million - AED 18 Million - AED 56 Million - AED 28 Million - AED 187 Million - AED 38 Million - AED 22 Million - AED 4 Million - AED 23 Million - AED 11 Million - AED 56 Million - AED 14 Million - AED 12 Million Page 2

Curriculum Vitae 2021

M/s Condor Building Contracting Co. LLC, Dubai, UAE Quantity Surveyor, March 2008 – March 2013 As Quantity Surveyor

Job responsibilities  Estimation, Enquiries, Quotations and Cost comparison statements  Quantity take-off, Preparation of Bills of Quantities  Preparing and finalizing Tender Documents  Attending to Tender Queries, Preparing Notice to Tenderers  Preparing Tender Analysis Reports for subcontract  Preparing formal Contract Documents for main and subcontract  Distribution of signed Contract Documents  Finalize subcontract agreement / contract  Evaluating project cost / benefits analysis at project decision point.

Reviewing shop drawings and as-built drawing.  Assists Contract Manager / Project Manager for Liaison with consultant in determining technical and contractual project issues.  Co-ordination with consultants, client & sub-contractor. Maintaining a high degree of professional skills& organizational behavior.  Exposure to Pre-contract, bidding and familiar with tender procedures.

Assisting Contract Manager for new tender bidding.  Evaluating project cost / benefits analysis at project decision point.

Reviewing shop drawings and as-built drawing.

Projects Completed • • • • • • • • • •

Pacific Clouds Data Centre Yahsat Satellite Ground Stations 3B+G+6 Storey Office building at Al Barsha 3B+G+1+R Workship building for Sikh Temple G+2 storey building for Dubai Silicon Oasis B+G+12 Commercial& Residential Bldg POP Exchange Bldgs 4 Nos for Du G+3 Residential Bldg at Al Warqaa G+1 Twin Villas 32nos at Mirdiff Hatta Hospital for DHA

- AED 190 Million - AED 263 Million - AED 75 Million - AED 57 Million - AED 65 Million - AED 56 Million - AED 25 Million - AED 17 Million - AED 59 Million - AED 86 Million

M/s Condor Building Contracting Co. LLC, Dubai, UAE Site Engineer, September 2007 – March 2008 Job responsibilities  Execution / Supervision of the site.  Arrangement of Materials.  Coordinating with the subcontractors.  Planning the works based on the approved base line program.  Correspondence / coordination with consultants  Negotiating and finalizing the Sub contractors  Preparing Sub-letting documents, Preparing Sub-contract documents,  Quantity take-off, Preparation of Bills of Quantities, Tender reports, Contract Documents  Correspondence / coordination with consultants  Preparing sub-contractor payment certificates, GREGORIOUS EBISON GOMEZ

Page 3

Curriculum Vitae 2021

As Site Engineer • G+1 Twin Villas 32nos at Mirdiff • Hatta Hospital for DHA

- AED 59 Million - AED 86 Million

M/s Konkan Petroleum Storage Site Engineer, September 2006 – September 2007 Job responsibilities  Execution / Supervision of the site.  Arrangement of Materials.  Coordinating with the subcontractors.  Planning the works based on the approved base line program.  Execution / Supervision of the site.  Arrangement of Materials.  Coordinating with the subcontractors.  Planning the works based on the approved base line program.

GREGORIOUS EBISON GOMEZ

Page 4

DEZIRE

PROJECT CONSULTANT

AREA OF EXPERTISE WE ARE EXPERT AT ;

COMMERCIAL

RESIDENTIAL

MIXED USE

UNIQUE PROJECT

HOSPITAL

INFRASTRUCTURE

COMMERCIAL

RESIDENTIAL

MIXED USE

INFRA PROJECTS

UNIQUE PROJECTS

UNIQUE PROJECTS

MAJOR CLIENT LIST

List of Projects Details 2018

DPC-Pre-Qualification

Project List and Scope of Services Project experience in the UAE and other Countries with outline scope of services provided Project Name

Year

Duration

Client

100%

Abu Dhabi

ECG

100%

Dubai

Techno steel Const

Al Ruwais Mall Extension

2018

2.

2018



2018



100%

Dubai

Khansaheb

4.

Cost Consultancy Service – Various Proj Fire, Ambulance and Police Point Buildings PN 1502 EXPO Village Development

2018



100%

Dubai

Shapoorji

5.

District 07, Meydan

2018



100%

Dubai

Azizi

6.

2B+G+10+R, Res

2018



100%

Dubai

Federal Consultant

7.

Private School Campus

2018



100%

Dubai

SRS

8.

Hartland - Phase 3 & Phase 4 Warehouse at DIP & Ras Al Khor Villa Project for Ms. Shamsa Lootah Deira Waterfront Development, Phase 1, Plot G+1+Roof Villa + Service Block Plot No 2270254 Yas Showroom Project Development B+G+2P+15+HC Commercial and Residential Building The 118, Business Bay

2018



100%

Dubai

Azizi

2018



100%

Dubai

Dubai Dawn

2018



100%

Dubai

Shamsa Lootah

2018



100%

Dubai

Khansaheb

2018



100%

Dubai

Future Art Engr’g Consultancy

2018



100%

Abu Dhabi

PMG

2018





100%

Dubai

Future Art Eng’gr Consultancy

2018





100%

Dubai

Signature DT Real Estate

Yas Showroom Project Development B+G+2P+15+HC Commercial and Residential Building The 118, Business Bay

2018



100%

Abu Dhabi

PMG

2018



100%

Dubai

Future Art Eng’gr Consultancy

2018



100%

Dubai

Signature DT Real Estate

9.

10.

11.

12.

13.

14.

15.

16.

17.

18.

Building

DEZIRE PROJECT CONSULTANT



Location

1.

3.

PostContract

% Complete (Pre contract)

PreContract 



 





List of Projects Details 2018

DPC-Pre-Qualification

Duration PrePostContract Contract  

% Complete (Pre contract)

Location

Client

100%

Dubai

SRS



100%

Abu Dhabi

SA Miro



100%

Dubai



100%

Dubai

2018



100%

Dubai

Belgravia 5 &Ellington Heights

2018



100%

Dubai

Vida Dubai Mall Project

2018



100%

Dubai

Project Name

Year

The Residence at JLT, Addition of Locker Room and Separate Building in the B5 Palace Villa

2018 2018



21.

Dubai Municipality Office Building at Hor Al Anz

2018



22.

Hotel Extension to Le Meridien Hotel

2018

23.

Golf Vita, DAMAC Hills

24.

25.

19.

20.



26.

Al Marjan IslandMovenpick Hotel & Resort

2018



100%

Ras Al Khaimah

27.

(B+G+3P+14+R) - Omeir Residential Building

2018



100%

Dubai

28.

482 National Houses

2018



100%

Ajman

29.

30.

31.

2B+G + 3P + 13 Typ. Residential PCFC HQ Building (3B+G+3P+16 Floors)Commercial Building

2018 2018 2018

  

100% 100% 100%

Dubai Dubai Dubai

32.

Movenpick Hotel Project

2018



100%

Dubai

33.

34.

35.

36.

Seven City, Jumeirah Lake Towers Marasi Riverside Residential Tower Dubai Opera Grande UCS Al Bada, Act One | Act Two on plots C1 & C2 at Downtown Dubai Development

2018 2018 2018 2018

   

100% 100% 100% 100%

Dubai Dubai Dubai Dubai

2018



100%

Dubai

37.

DEZIRE PROJECT CONSULTANT

 



Aroma International Contracting Khansaheb China State Construction Engineering Aroma International Contracting China State Construction Engineering Global Green Bridge Contracting East West Building Contracting China State Construction Engineering Dubai Dawn Khansaheb Al Shafar National China State Construction Engineering HO-Airolink Khansaheb Shapoorji Archdome Consulting China State Construction Engineering

List of Projects Details 2018

DPC-Pre-Qualification

Dubai Municipality Project Project Name

Year

Consultant

Project Category

Consultant’s Role

1.

PJ-10099 Multi-storey Car Park (G+5)

2018

Dubai Municipality

Category 4

Post Contract

2.

PJ-30032 234 Villas at Oud Al Muteena and Al Quoz

2018

Dubai Municipality

Category 4

Post Contract

3.

PJ 30034/1 Al Ahli Stadium Extension & PJ 30034/2 Humaid Al Tayer Stadium

2018

Dubai Municipality

Category 4

Post Contract

Al Wasl Project Project Name

Year

Consultant

Project Category

Consultant’s Role Post Contract

1

R1081 Ras Al Khor Phase 1

2018

Engineering Consortium

Category 4

2

R1088 Al Qusais Residential Development

2018

Arkiplan

Category 4

3

G+4+R Residential Building at Al Karama

2018

Landmark Engineering

Category 4

4

P525 - WASL R1092 – Warsan Residential Development 2018 Plot No 8111444 Warsan

Design Center

Category 14

Budget/Cost plan/Tender Documents/Tender Evaluation/Contract Documents/Provisional sum/Post Contract Budget/Cost plan/Tender Documents/Tender Evaluation/Contract Documents/Post Contract Budget/Cost plan/Tender Documents/Tender Evaluation/Contract Documents/Post Contract

TECOM-Tamdeen Project Project Name

Year

Project Value (AED)

Project Category

1.

PT-182/4 Office Building

2018

-

Category 5

2.

Cost Consultancy Services – Various Project

2018

-

Category 4

DEZIRE PROJECT CONSULTANT

Consultant's Role Budget/Cost plan/Tender Documents/Tender Evaluation/Contract Documents/Provisional sum Post Contract

List of Projects Details 2019

DPC-Pre-Qualification

Project List and Scope of Services Project experience in the UAE and other Countries with outline scope of services provided Project Name 1.

Duration

% Complete (Pre contract)

Location

Client

100%

Abu Dhabi

Sobha



100%

Dubai

Khansaheb



100%

Dubai

Kannoun Architects

PreContract 

PostContract

3.

Kizad Steel Factory at Khalifa Industrial Zone JH-0013 Madinat Jumeriah Living - Sales Cluster (Design & Build) Villa is a G+1 at Al Khawaneej first

4.

Al Nakhali Lodges – Gym and Spa Building



100%

Dubai

Khansaheb

5.

G+14+3P+2B – Building



100%

Dubai

Family Star Construction

6.

Project G+6 Residential & Retail Building



100%

Dubai

Vincitore

7.

Kizad Steel Factory at Khalifa Industrial Zone



100%

Abu Dhabi

Sobha

8.

Opus Hotel



100%

Dubai

Opus HM Limited



100%

Dubai

Sobha Electromechanical Works

 

100%

Dubai



100%

Dubai



60%

Dubai



80%

Dubai

Khansaheb Civil Engineering Aroma International Building Contracting Aroma International Building Contracting Aroma



100%

Dubai

Afcons Construction Mideast LLC



100%

Dubai

100%

Dubai



100%

Dubai



100%

Dubai

AKD Consulting Engineers Future Art Engineering Consultancy A.E Prime Engineering Consultants China State Construction Engrg.

Corp.

2.

10.

RIT-Construction of Rochester Institute of Technology Campus PT-234/4 University of Birmingham, DIAC

11.

Off-Campus Student Housing on Plot no. 812-287

9.

15.

Commercity, Business Cluster Phase 1, Umm Ramool, Works Phase Logistics Cluster, Works Phase 1 R 1005/1 - Improvement of Al Awir Road & International City Accesses Zawaya on Plot No. 674-313

16.

B+G+1 Commercial Building on Plot No. 2410282



17.

Manazel Residence (G+2+Roof) on Plot 01-014



18.

ACT ONE | ACT TWO ON PLOTS C1 & C2

12.

13.

14.

DEZIRE PROJECT CONSULTANT



  

List of Projects Details 2019

DPC-Pre-Qualification Project Name 19.

20.

21.

Cleveland Clinic Abu Dhabi DG 002 Top Golf Emirates Golf Club Development R1010–Wasl Jumeirah Beach Resort and Spa & R1030 – Hyatt Place Mina – Capitalization

PreContract

Duration

PostContract

  

22.

Visa Cemea HQ (4B+G+5+R)

23.

Secondment for QS Services

24.

Al Mamzar Byblos Hotel, Plot No 1340985



25.

WTC Mosque



 



% Complete (Pre contract)

Location

100%

Abu Dhabi

Client Khansaheb A.E Prime Engineering Consultants Design & Architects Bureau (DAR)

100%

Dubai

100%

Dubai

100%

Dubai

Khansaheb

100%

Dubai

Jumeirah Golf Estates LLC

100%

Dubai

MAE Electromechanical Works

85%

Abu Dhabi

X-Architects

Al Wasl Project Project Name 1

R1068 Hotel Staff Accommodation

2

Cost Consultancy Services – Various Project

DEZIRE PROJECT CONSULTANT

Consultant

Project Category

Consultant’s Role

Al Wasl Al Jadeed

Category 10

Budget/Cost plan/Tender Documents/Tender Evaluation/Contract Documents/Post Contract

Al Wasl

Category 4

Post Contract

List of Projects Details 2020

DPC-Pre-Qualification

Project List and Scope of Services Project experience in the UAE and other Countries with outline scope of services provided Project Name 1.

2.

3.

4.

5.

6.

7.

8.

YMZ Studios - (Design & Build) Fit Out Main Construction Services PJ0041 - Modification Works at Dubai Hospital (Phase-2) Residential Building - G + 2P + 1st Floor (Residential & HC with Swimming Pools) + 7

Duration

% Complete (Pre contract)

Location

Client



100%

Abu Dhabi

Khansaheb Civil Engineering



100%

Dubai

ARC International Engineering Consultants



65%

Dubai

Dubai Dawn



100%

Dubai

Next Engineering Consultants





100%

Dubai

Techno Steel Construction





100%

Dubai

Future Art Engineering Consultancy

100%

Dubai

Khansaheb

100%

Al Dhaid Sharjah

Al Burj Engineering Consultants

PreContract



PostContract

Typ. Floors + R+ UR

Blue water Wharf Retail Enhancement Project - Project no. MH-0054 P42 Umm Ramool Development Plot No. 215 115 Swimming Pool Block on Plot No. 2514122 HHS Rashid Bin Mohammed Bin Rashid Mosque Consultancy Services for Design and Supervision of Filling Stations



 



9.

Warner Brothers Hotel, Yas Island



100%

Abu Dhabi

Shapoorji Pallonji Mideast LLC

10.

Construction of Mosque at JAPS



100%

Dubai

DBB Contracting



100%

Dubai

Vision Construction LLC



100%

Dubai

Khansaheb



100%

Dubai

PluMech Engineering Consultants



100%

Dubai

AH Investments LLC



100%

Dubai

DIP Development CO LLC

11.

12.

13.

14.

15.

M2229/3 Development works at Al Warsan F/V Market Construction of HHS Shekha Bint Saeed Al Maktoum Mosque PH - Barn House W1104 –South Heights, Al Badaa & W 1105 – Al Qusais Heights B+G+1 Building on Plot 598 - 620 in DIP

DEZIRE PROJECT CONSULTANT



List of Projects Details 2020

DPC-Pre-Qualification Project Name 16.

17.

18.

19.

20.

21.

22.

23.

B+G+1+Roof Jumeirah Bay House Villa B+G+M+2+Roof Commercial & Residential, Plot no. 2150187 Nest Student Accommodation at Block M of Aljada Expo Pavilion - Thailand Proposed modification to existing warehouse to Honda/FCA Service Center Proposed modification Nest Student Accommodation at Block M of Aljada 4B+G+4P+10TYP+R Residential Building on Plot No: 6730911 TP10 Al Raffa Development – B+G+7 Residential Building

PreContract 

Duration

PostContract







% Complete (Pre contract)

Location

Client

100%

Dubai

100%

Dubai

100%

Dubai

Khansaheb Civil Engineering Al Anwar Architectural Engineering Consultants China State Construction Engrg.

Corp.





100%

Dubai

Arcade Star Construction





65%

Dubai



100%

Dubai

Aroma International Building Contracting



50%

Dubai

CJ TEC Contracting LLC



100%

Dubai

Khansaheb

FACE Architecture & Design

24.

COEX Campus



100%

Dubai

Khansaheb Civil Engineering

25.

Walls and Wall finishes at Youth Store at MOE



100%

Dubai

Khansaheb

26.

Opera District Downtown Dubai A-Plots Cascade Parking



100%

Dubai

Khansaheb

DHA – Dubai Health Authority Project Name

Project Category

Consultant's Role

1.

IPR 12061554 Third Party Consultant Service - Abu Hail Health Center

Category 7

Third Party Evaluation

2.

IPR 12061556/AFZ -Third Party Consultant service - Al Qusais Health Center

Category 7

Third Party Evaluation

3.

IPR-12061558/AFZ Third Party Consultant Service - Umm Suqaim Health Center

Category 7

Third Party Evaluation

DEZIRE PROJECT CONSULTANT

List of Projects Details 2021

DPC-Pre-Qualification

Project List and Scope of Services Project experience in the UAE and other Countries with outline scope of services provided No. 1.

2.

Project Name R -1045 – Creek View Residential Development for Wasl properties Emarat Filling Stations at various locations for Emarat

3.

Maryam Gate Residences for Eagle Hills

4.

F -1017 – Wasl Gate, G+1 Gardenia Townhomes II for Wasl properties

5.

Proposed Metal Park for Abu Dhabi Ports PJSC

6.

7.

PJ-0011 - G+3 service (A) & B+G+4 Outpatient Clinics Buildings (B) Expansion at Dubai Hospital Commercial/ Residential Building (2B+G+M+1st+3Typ.Floor+5th+Roof+ Upper Roof)

PreContract

Duration

PostContract

% Complete (Pre contract)

Location

Client



A.E Prime Engineering Consultants



Al Burj Engineering Consultants



China State Construction Arkiplan Consulting Architects & Engineers

 

Al Wasl Al Jadeed Consultants



DHA – Dubai Health Authority





Distinguished Real Estate



Al Wasl Al Jadeed Consultants



8.

VIVA Distribution Center for Landmark Group



9.

Masdar City Campus - MC2



10.

IPR 12061554 - Abu Hail Health Center



DHA – Dubai Health Authority

11.

IPR 12061556/AFZ -T - Al Qusais Health Center



DHA – Dubai Health Authority

12.

IPR-12061558/AFZ - Umm Suqaim Health Center



DHA – Dubai Health Authority

13.

Firmeinch PT-233/1 Offices & Labs Building



TECOM / Al Ashram Contracting

14.

Construction, Completion and Maintenance of Proposed 2B+G+5+R Commercial and Residential Building on Plot No. 123-1101 at Al Muteena



Al Ashram Contracting

DEZIRE PROJECT CONSULTANT

DBB Contracting LLC

List of Projects Details 2021

DPC-Pre-Qualification No. 15.

16.

17.

18.

19.

Project Name AD-9070 Belgravia 3 (G+P+4+R) residential Building on plot no. JVC15HMRP200 Al Barsha South Fourth Construction of Proposed Residential and Commercial Building G+11+R Oud Metha, Dubai Tilal Al Ghaf (TAG) Retail Hub Phase 1 Construction OF Phase 1 AT Block J, Aljada (8 buildings) R1038 - Tiara Hotel on Plot No. 381-0101 at Nakhlat Jumeirah

PreContract

22.

Wet Deck at WESTIN Hotels and Resorts



23.

PJ-30049 Juvenile Center



24.

Villa at Nadd Al Shilba and Villa at Al Wasl



Third Party Quantity Surveying Services

29.

ELI- Kensington Waters SH3

DEZIRE PROJECT CONSULTANT



Al Ashram Contracting



Al Ashram Contracting





28.

Client

Al Ashram Contracting

T083-21 Design & Cons Active Padel Courts Al Maryah

27.

Location



21.

26.

% Complete (Pre contract)

Khansaheb

EXPO 2020 Project

Refurbishment of Shekha Hessa Villa in Zaabeel Palace Construction of Ladies Staff Accommodation, Parking Building at Zaabeel Construction of Kitchen Extension at Al Lissaili Villa

PostContract



20.

25.

Duration



Engineering Consortium Consulting Engineers Dar Al-Omran Engineering Consultants DUTCO Construction Co LLC Design Center Architects & Engineers Consultants Bin Dalmouk Engineering Consultants ZAD Studio Architectural Consultancy



Khansaheb



Khansaheb



Khansaheb 



DAMAC Properties Co. LLC, DBB Contracting LLC

2nd Cycle Mohammed Bin Rashid Al Maktoum Business Innovation Award

Dezire Project Consultant DEZIRE PROJECT CONSULTANT March, 2019

2nd Cycle of the Mohammed Bin Rashid Al Maktoum Business Innovation Award Version No. 02

DC.BSD.T11.14

Issue Date: 05 April 2016

1 of 11

CONCLUSION The MRM Business Innovation Award assessment team had the privilege to assess DPC’s submission for the 2nd Cycle of the Mohammed Bin Rashid Al Maktoum Business Innovation Award. The organization’s desire for innovation excellence was evident throughout the assessment process and during the site visit.

The assessment team has observed great effort and enthusiasm by the Company management especially the founder and CEO Ms. Sinimol Noushad leading from the front and staff in their pursuit of innovation excellence. This was clearly evident all across the organization. During the opening meeting, the senior management shared the Company innovation excellence journey as a part of the overall pursuit of its business objectives and outperformance. It was apparent that leaders were behind embedding innovation excellence into the organization culture. Subsequent interactions with various senior personnel and interviews of relevant staff have led the assessors to a similar conclusion.

The team would like to place on record its appreciation to DPC for putting together the submission document and ensuring a very successful site visit. The team would like to take this opportunity to wish the Company the very best in its journey of innovation excellence and hope the feedback provided in this report will assist the organization further in its innovation excellence journey.

2nd Cycle of the Mohammed Bin Rashid Al Maktoum Business Innovation Award Version No. 02

DC.BSD.T11.14

Issue Date: 05 April 2016

11 of 11

1208 Regal Tower, Business Bay, Dubai, UAE