CITY OF SANTA BARBARA NOTICE TO CONTRACTORS BID NO. 5442 Sealed proposals for Bid No. 5442 for the CABRILLO AND ALAMEDA PADRE SERRA WATERLINE REPLACEMENT PROJECT will be received in the Purchasing Office, 310 E. Ortega Street, Santa Barbara, California 93101, until 3:00 p.m., Tuesday April 19, 2016 to be publicly opened and read at that time. Any bidder who wishes its bid proposal to be considered is responsible for making certain that its bid proposal is actually delivered to said Purchasing Office. Bids shall be addressed to the General Services Manager, Purchasing Office, 310 E. Ortega Street, Santa Barbara, California, and shall be labeled, “CABRILLO AND ALAMEDA PADRE SERRA WATERLINE REPLACEMENT, Bid No. 5442". The work includes all labor, material, supervision, plant and equipment necessary to complete the following: Install municipal water mains ranging in size from 2 inch copper to 12 inch PVC and ductile iron. The majority of the project is 8-inch PVC and ductile iron. The replacements occur at two areas. There are 3 contingency locations that are mostly 12” water mains. The project total length including all contingency locations is about 2.2 miles. The Engineer’s estimate is $2,850,000. Each bidder must have a Class 'A' license to complete this work in accordance with the California Business and Professions Code. There is a mandatory Pre-Bid meeting scheduled for Monday April 11th 2016 at 10am at 620 Garden St Santa Barbara Ca David Gebhard Conference Room. The plans and specifications for this Project are available electronically at SantaBarbaraCA.gov/ebidboard. Plan and specification sets can be obtained from CyberCopy (located at 504 N Milpas St, cross street Haley) by contacting Alex Gaytan, CyberCopy Shop Manager, at (805) 884-6155. The City’s contact for this project is Carson Wollert, Project Engineer, 805-564-5376. In order to be placed on the plan holder’s list, the Contractor can register as a document holder for this Project on Ebidboard. Project Addendum notifications will be issued through Ebidboard.com. Although Ebidboard will fax and/or email all notifications once they are provided contact information, bidders are still responsible for obtaining all addenda from the Ebidboard website or the City’s website at: SantaBarbaraCA.gov/ebidboard. Bidders are hereby notified that pursuant to provisions of Section 1770, et seq., of the Labor Code of the State of California, the Contractor shall pay its employees the general prevailing rate of wages as determined by the Director of the Department of Industrial Relations. In addition, the Contractor shall be responsible for compliance with the requirements of Section 1777.5 of the California Labor Code relating to apprentice public works contracts. Per California Civil Code Section 9550, a payment bond in the amount of 100% of the bid total will be required from the successful bidder for bids exceeding $25,000. The bond must be provided within 10 calendar days from notice of award and prior to the performance of any work. The proposal shall be accompanied by a proposal guaranty bond in the sum of at least 10% of the total amount of the proposal, or alternatively by a certified or cashier’s check payable to the Owner in the sum of at least 10% of the total amount of the proposal. A separate performance bond in the amount of 100% of the bid total will be required from the successful bidder. The bond must be provided within 10 calendar days from the notice to award and prior to the performance of any work. Effective March 1, 2015, Senate Bill 854 requires the City to only use contractors and subcontractors on public projects that have been registered with the State of California Department of Industrial Relations. A contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. It is not a violation of this section for an unregistered contractor to submit a bid that is authorized by Section 7029.1 of the Business and Professions Code or by Section 10164 or 20103.5 of the Public Contract Code, provided the contractor is registered to perform public work pursuant to Section 1725.5 at the time the contract is awarded. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. The City of Santa Barbara hereby notifies all bidders that it will affirmatively insure that in any purchase order entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, creed, color, national origin, ancestry, sexual orientation, political affiliations or beliefs, sex, age, physical disability, medical condition, marital status or pregnancy as set forth hereunder. GENERAL SERVICES MANAGER CITY OF SANTA BARBARA William Hornung, C.P.M. PUBLISHED: March 30 and April 6, 2016 Montecito Journal
46 MONTECITO JOURNAL
FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Sharon Goldberg MD, 5333 Hollister Avenue, Suite 175, Santa Barbara, CA 93111. Sharon Goldberg, 549 Via Tranquila, Santa Barbara, CA 93110. This statement was filed with the County Clerk of Santa Barbara County on March 21, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Tara Jayasinghe. FBN No. 2016-0000864. Published March 30, April 6, 13, 20, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Santa Barbara Speaks, 549 Via Tranquila, Santa Barbara, CA 93110. Gabriela Goldberg, 549 Via Tranquila, Santa Barbara, CA 93110. Sharon Goldberg, 549 Via Tranquila, Santa Barbara, CA 93110. Zoe Reifel, 3824 Lincoln Road, Santa Barbara, CA 93110. This statement was filed with the County Clerk of Santa Barbara County on March 16, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Christine Potter. FBN No. 2016-0000812. Published March 30, April 6, 13, 20, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: DPK Construction, 90 Arnold Place Unit C, Goleta, CA 93117. Douglas P. Krol, 3033 Calle Noguera, Santa Barbara, CA 93105. This statement was filed with the County Clerk of Santa Barbara County on February 23, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Tara Jayasinghe. FBN No. 2016-0000559. Published March 23, 30, April 6, 13, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: NextHome Properties, 988 Fredensborg Canyon Road, Solvang, CA 93463. Decker Realty, INC, 988 Fredensborg Canyon Road, Solvang, CA 93463. This statement was filed with the County Clerk of Santa Barbara County on March 7, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Christine Potter. FBN No. 2016-0000696. Published March 23, 30, April 6, 13, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: T3 Property Management, 988 Fredensborg Canyon Road, Solvang, CA 93463. Decker Realty, INC, 988 Fredensborg Canyon Road, Solvang, CA 93463. This statement was filed with the County Clerk of Santa Barbara County on March 16, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Adela Bustos. FBN No. 2016-0000815. Published March 23, 30, April 6, 13, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: NextHome Properties; T3 Property Management, 988 Fredensborg Canyon Road, Solvang, CA 93463. Steven Corl Decker, 988 Fredensborg Canyon Road, Solvang, CA 93463. This statement was filed with the County Clerk of Santa Barbara County on March 16, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Adela Bustos.
FBN No. 2016-0000816. Published March 23, 30, April 6, 13, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Next Chapter SB Properties, 1482 E. Valley Rd #300, Santa Barbara, CA 93108. Gregory Pavloff, 1482 E. Valley Rd #300, Santa Barbara, CA 93108; Robert Pavloff, 1482 E. Valley Rd #300, Santa Barbara, CA 93108. This statement was filed with the County Clerk of Santa Barbara County on February 29, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Jan Morales. FBN No. 2016-0000594. Published March 23, 30, April 6, 13, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Bridal Bootycamp, 1 North Calle Cesar Chavez Street, Suite 110, Santa Barbara, CA 93103. Elizabeth Alexander, 421 West Anapamu Street Apt. C, Santa Barbara, CA 93101. This statement was filed with the County Clerk of Santa Barbara County on March 3, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Adela Bustos. FBN No. 2016-0000668. Published March 16, 23, 30, April 6, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Prestigious Properties & Investments, 628 Vereda Del Ciervo Drive, Goleta, CA 93117. P.P.I. Realty Investments, INC., 628 Vereda Del Ciervo Drive, Goleta, CA 93117. This statement was filed with the County Clerk of Santa Barbara County on February 23, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Tara Jayasinghe. FBN No. 2016-0000546. Published March 16, 23, 30, April 6, 2016. FICTITIOUS BUSINESS NAME STATEMENT OF ABANDONMENT: The following person(s) has (have) abandoned the use of the Fictitious Business Name(s): Ocean Aire, 125 Harbor Way Suite 7, Santa Barbara, CA 93109. Jon Payne, 6 Harbor Way #239, Santa Barbara, CA. This statement was originally filed with the County Clerk of Santa Barbara County on June 4, 2015. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Jan Morales, filed March 8, 2016. Original FBN No. 2015-0001804. Published Published March 16, 23, 30, April 6, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: Ocean Aire, 125 Harbor Way #7, Santa Barbara, CA 93109. Allied Voyage LLC, 125 Harbor Way #7, Santa Barbara, CA 93109. This statement was filed with the County Clerk of Santa Barbara County on March 8, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file in my office. Joseph E. Holland, County Clerk (SEAL) by Jan Morales. FBN No. 2016-0000724. Published March 16, 23, 30, April 6, 2016. FICTITIOUS BUSINESS NAME STATEMENT: The following person(s) is/are doing business as: AG Builders, 960 Veronica Springs Rd, Santa Barbara, CA 93105. Iran Alexis Gonzalez, 960 Veronica Springs Rd, Santa Barbara, CA 93105. This statement was filed with the County Clerk of Santa Barbara County on March 8, 2016. This statement expires five years from the date it was filed in the Office of the County Clerk. I hereby certify that this is a correct copy of the original statement on file
• The Voice of the Village •
in my office. Joseph E. Holland, County Clerk (SEAL) by Christine Potter. FBN No. 2016-0000715. Published March 16, 23, 30, April 6, 2016.
Deputy Clerk. Hearing date: May 18, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/16, 3/23, 3/30, 4/6
ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00752. To all interested parties: Petitioner Ernesto Vladimir Landa filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name to Vladimir Landa. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Filed March 4, 2016 by Terri Chavez, Deputy Clerk. Hearing date: May 18, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/23, 3/30, 4/6, 4/13
ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00700. To all interested parties: Petitioners Nadia Lash and Valentin Lash filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name from Emiliya Lyash to Emily Lash. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Filed March 1, 2016 by Terri Chavez, Deputy Clerk. Hearing date: April 27, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/16, 3/23, 3/30, 4/6
ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00787. To all interested parties: Petitioner Gabriela GuzmanMorales filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name to Gabriela Morales. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Filed March 4, 2016 by Terri Chavez, Deputy Clerk. Hearing date: May 18, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/16, 3/23, 3/30, 4/6
ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00793. To all interested parties: Petitioner Amy Michelle Benson filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name to Samantha Dean. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Hearing date: May 18, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/9, 3/16, 3/23, 3/30
ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00610. To all interested parties: Petitioner Tara Judith Patrick Nack filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name to Tara Judith Patrick. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Filed March 4, 2016 by Terri Chavez, Deputy Clerk. Hearing date: April 27, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/16, 3/23, 3/30, 4/6 ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00706. To all interested parties: Petitioner Eudelia Dee Zamora filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name to Eudelia Dee Raya. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Filed February 20, 2016 by Terri Chavez,
ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00611. To all interested parties: Petitioners Jennifer Bower and Norman Hannotte filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing name from Wynona Grace Hannotte to Wynona Grace Joey Hannotte. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Hearing date: April 13, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/9, 3/16, 3/23, 3/30 ORDER TO SHOW CAUSE FOR CHANGE OF NAME: CASE No. 16CV00420. To all interested parties: Petitioner Vito Anthony Summa IV filed a petition with Superior Court of California, County of Santa Barbara, for a decree changing to Vito Anthony Kait Summa. The Court orders that all persons interested in this matter appear before this court at the hearing indicated below to show cause, if any, why the petition for change of name should not be granted. Any person objecting to the name changes described above must file a written objection that includes the reasons for the objection at least two court days before the matter is scheduled to be heard and must appear at the hearing to show cause why the petition should not be granted. If no written objection is timely filed, the court may grant the petition without a hearing. Filed February 19, 2016 by Terri Chavez, Deputy Clerk. Hearing date: April 13, 2016 at 9:30 am in Dept. 1, 1100 Anacapa Street, Santa Barbara, CA 93101. Published 3/9, 3/16, 3/23, 3/30
31 March – 7 April 2016