Public Notices

The Work is expected to be commenced within thirty (30) days after the Date of Contract.

Bid Security in the amount of five percent (5%) of the total Bid Price must accompany each Bid in the form specified in the Instructions to Bidders.

The Successful Bidder will be required to furnish a Performance Bond, Labor and Material Payment Bond guaranteeing faithful performance and warranty bond for two-years after Substantial Completion, and the payment of all bills and obligations arising from the performance of the Contract.

The OWNER reserves the right to award the contract by sections, to reject any or all Bids, and to waive any informalities and irregularities therein.

For further information, please contact Barney Fix at Merrick & Company at 303-751-0741.

Legal Notice No. CCX1084

First Publication: June 22, 2023

Last Publication: July 6, 2023

Publisher: Commerce City Sentinel Express Non-Consecutive Publications

Public Notice

NOTICE OF FINAL PAYMENT

NOTICE is hereby given that the South Adams County Water and Sanitation District (“District”) of Adams County, Colorado, will make final payment at its offices at 6595 E. 70th Avenue, Commerce City, Colorado, 80022, on July 17, 2023, at the hour of 3:00 p.m. to Brannan Construction Company of Denver, CO for all work done by said Contractor(s) in construction work performed for the District.

Project Contractor:

Brannan Construction Company

Project Name: 2023 SACWSD PZ21 Development Conversion to Irrigation System

Project Location: Primarily located on Potomac Street between E 104th Avenue and E 108th Avenue and side streets. Other work areas were in various locations in the surrounding areas of the developments adjacent to Potomac Street.

Any person, co-partnership, association of persons, company or corporation that has furnished labor, materials, team hire, sustenance, provisions, provender, or other supplies used or consumed by any contractors or their subcontractors, in or about the performance of the work contracted to be done or that supplies rental machinery, tools, or equipment to the extent used in the prosecution of the work, and whose claim therefor has not been paid by the contractors or their subcontractors, at any time up to and including the time of final settlement for the work contracted to be done, is required to file a verified statement of the amount due and unpaid, and an account of such claim, to the District at the above address, Attn: Dawn Fredette, District Clerk, on or before the date and time hereinabove shown. Failure on the part of any claimant to file such verified statement of claim prior to such final settlement will release the District, its Board of Directors, officers, agents, and employees, of and from any and all liability for such claim.

All of the above is pursuant to §38-26107, C.R.S.

BY ORDER OF THE BOARD OF DIRECTORS

SOUTH ADAMS COUNTY WATER AND SANITATION DISTRICT acting through its SOUTH ADAMS COUNTY WATER AND SANITATION DISTRICT ACTIVITY ENTERPRISE

By:Vicki Ennis Secretary

Legal Notice No. CCX1086

First Publication: June 29, 2023

Last Publication: July 6, 2023

Publisher: Commerce City Sentinel Express

Public Notice

FINAL SETTLEMENT

Project Title: Painted Prairie Subdivision Filing No. 3, On-Site Lighting and Electrical

Project Owners: Painted Prairie Public Improvement Authority

Project Location: City of Aurora, Adams County

The Painted Prairie Public Improvement Authority plans to accept the above titled project as substantially complete and for Final Settlement to Communication

Construction & Engineering, Inc. after July 24, 2023. In accordance with the Contract Documents, the Painted Prairie Public Improvement Authority may withhold a portion of the remaining payment to be made to Communication Construction & Engineering, Inc., as necessary, to protect the Painted Prairie Public Improvement Authority from loss on account of claims filed and failure of Communication Construction & Engineering, Inc. to make payments properly to subcontractors or suppliers. Project suppliers and subcontractors of Communication Construction & Engineering, Inc. are hereby notified that unresolved outstanding claims must be certified and forwarded to:

Contact Person: Barney Fix, P.E.

Address: 5970 Greenwood Plaza Blvd. Greenwood Village, CO 80111 as soon as possible, but no later than July 20, 2023.

Legal Notice No. CCX1081

First Publication: June 22, 2023

Last Publication: July 6, 2023

Publisher: Commerce City Sentinel Express

Non-Consecutive Publications

Public Notice

Painted Prairie Public Improvement Authority

Painted Prairie Town Center Streetscape Landscape

Sealed Bids will be received by Painted Prairie Public Improvement Authority, hereinafter referred to as OWNER, at the office of the Authority Engineer, Merrick & Company, 5970 Greenwood Plaza Boulevard, Greenwood Village, CO 80111, until 11:00 AM local time on July 20, 2023 for:

Painted Prairie Town Center Streetscape Improvements

This Contract provides for the construction of the following: Streetscape irrigation and landscaping improvements.

Copies of the Bidding Documents may be requested from the Painted Prairie Public Improvement Authority, at the email of the Authority Engineer, barney.fix@ merrick.com, beginning June 22, 2023. NO PAYMENT REQURIED.

Bidders must be licensed Contractors in the State of Colorado.

Bids will be received providing unit price for items; however, the price given will be on a maximum not-to-exceed amount, as described in the Bidding Documents.

The Work is expected to be commenced within thirty (30) days after the Date of Contract.

Bid Security in the amount of five percent (5%) of the total Bid Price must accompany each Bid in the form specified in the Instructions to Bidders.

The Successful Bidder will be required to furnish a Performance Bond, Labor and Material Payment Bond guaranteeing faithful performance and warranty bond for two-years after Substantial Completion, and the payment of all bills and obligations arising from the performance of the Contract.

The OWNER reserves the right to award the contract by sections, to reject any or all Bids, and to waive any informalities and irregularities therein.

For further information, please contact Barney Fix at Merrick & Company at 303-751-0741.

Legal Notice No. CCX1083

First Publication: June 22, 2023

Last Publication: July 6, 2023

Publisher: Commerce City Sentinel Express Non-Consecutive Publications

Summons and Sheriff Sale

Public Notice

DISTRICT COURT, ADAMS COUNTY, COLORADO

Court Address: 1100 Judicial Center Drive

Brighton, 80601

Plaintiff: FRONTERRA VILLAGE FILING NO.3 HOMEOWNERS ASSOCIATION, INC., a Colorado nonprofit corporation; Defendants: JOSEPH S. MENDIOLA; PENNYMAC LOAN SERVICES, LLC; ADAMS COUNTY TREASURER; UNKNOWN TENANT(S) IN POSSESSION.

Case Number: 2023CV30329

Attorneys for Plaintiff: THE DUPONT LAW FIRM, LLC Stephane R. Dupont, #39425

Address: PO Box 1073, Castle Rock, CO 80104

Phone Number: (720) 644-6115

SUMMONS BY PUBLICATION

THE PEOPLE OF THE STATE OF COLORADO

TO THE ABOVE NAMED

DEFENDANT(S): Joseph S. Mendiola

You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the court in this action, by filing with the clerk of this court an Answer or other response. You are required to file your Answer within 35 days after the service of this Summons upon you. Service of the Summons shall be complete on the day of the last publication. A copy of the Complaint may be obtained from the clerk of the court.

If you fail to file your answer or other response to the Complaint in writing within 35 days after the date of the last publication, judgment by default may be rendered against you by the court for the relief demanded in the Complaint without further notice.

This is an action for judicial foreclosure of an association assessment lien pursuant to C.R.S. 38-33.3-316, in and to real property situated in Adams County, Colorado, more particularly described on Exhibit A, attached hereto and by this reference made a part hereof.

Dated: May 18, 2023

THE DUPONT LAW FIRM, LLC

By: *s/ Stephane R. Dupont Stephane R. Dupont

This Summons is issued pursuant to Rule 4(h), Colorado Rules of Civil Procedure Exhibit A

Lot 8, Block 15, Fronterra Village Filing No. 3, County of Adams, State of Colorado.

Also known as: 16483 East 98th Way, Commerce City, CO 80022

Legal Notice No. CCX1071

First Publication: June 8, 2023

Last Publication: July 6, 2023

Publisher: Commerce City Sentinel Express ##