Starting a new business?

Rosemead City Notices

Go to filedba.com CITY OF ROSEMEAD NOTICE INVITING BIDS NIB No. 2023-08

NOTICE IS HEREBY GIVEN that the CITY OF ROSEMEAD, California, will receive electronic bids through PlanetBids at: https:// pbsystem.planetbids.com/portal/54150/portal-home OR sealed bids at the City Clerk’s office, City Hall, 8838 Valley Blvd, Rosemead, CA 91770 up to 10:30 o’clock a.m. on Tuesday, the 18th day of April, 2023. Electronic and hardcopy bids will be publicly posted on PlanetBids and City’s website.

ARTERIAL STREET PAVEMENT REHABILITATION PROJECT No. 43010

The project consists of removing and replacing existing AC Pavement, adjusting manhole covers, water valve covers, and gas covers to grade. Project also includes removal and replacement of raised pavement markers, striping, and traffic signal loops to match existing, as well as miscellaneous work as indicated on the construction plans, including other incidental and appurtenant work necessary for the proper completion of the project.

The engineer’s estimate for this project is in the range of $3,500,000. The successful bidder shall have THIRTY (30) working days including material procurement to complete the work. Liquidated damages shall be $500.00 per calendar day.

Copies of the Bidding and Contract Documents, Plans and Specifications can be obtained from the City’s PlanetBid portal. Contractors can register as a vendor and download the documents by visiting the PlanetBid Portal (https://pbsystem.planetbids.com/ portal/54150/portal-home). Hard copy of the bid package will not be mailed.

SB 854 Requirements:

This project is subject to the requirements of SB 854. No prime contractor or subcontractor may be listed on a bid proposal for a public works project unless registered and qualified with the Department of Industrial Relations pursuant to Labor Code section 1725.5. No prime contractor or subcontractor may be awarded a contract for public work on a public works project unless registered and qualified with the Department of Industrial Relations pursuant to Labor Code section 1725.5. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. The bid proposal must include a print out from the DIR registration website showing that the prime contractor and each subcontractor is currently registered and qualified. No bid proposals will be accepted nor any contract entered into with a prime contractor without proof of registration as required above. [Unless within the limited exceptions from this requirement for bid proposals only under Labor Code Section 1771.1(a)]

Each bid must be accompanied by a bidder’s security in an amount not less than 10% of the amount of the bid, as a guarantee that the bidder will, if awarded the Contract, enter into a satisfactory agreement and provide a Performance Bond and a Payment Bond, each not less than 100% of the total amount of the bid price.

No bidder may withdraw his bid for a period of sixty-one (61) days after the above bid opening date.

The CITY OF ROSEMEAD will affirmatively ensure the disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, disability, sex or national origin in the consideration for an award.

Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Compliance with the prevailing rates of wage and apprenticeship employment standards established by the State Director of Industrial Relations will be required.

Bidders shall be licensed in accordance with the provision of Chapter 9, Division 111 of the Business and Professions Code of the State of California. Bidder shall have a Class “A” license in good standing at the time Bids are received.

The Council reserves the right to reject any and all bids and to waive any informality, technical defect, or minor irregularity in any bid submitted.

An award of service shall not be final until the bids have been reviewed and a Contract Agreement with the City has been signed by the lowest responsible bidder and by the City.

Award of Contract Agreement is proposed for April 25th, 2023.

All questions regarding this bid shall be uploaded City’s portal on PlanetBids, no later than 10 calendar days prior to bid due date and time.

Dated this March 23, 2023

Ericka Hernandez City Clerk

Publish: March 27th & April 3rd, 2023.

ROSEMEAD READER

Temple City Notices

Notice

Recruitment For City Of Temple City City Commissioners

Applications accepted through April 28

April 3, 2023 – The City of Temple City is accepting applications to fill positions on the following commissions for a two-year term effective July 1, 2023:

• Three seats on the Planning Commission, which has decisionmaking authority over a variety of development proposals. Commissioners advise the city council on programs, policies and issues relating to planning, development and land-use regulation. The commission meets on the second and fourth Tuesdays of the month at 7:30 p.m.

Three seats on the Parks and Recreation Commission, which delivers recommendations to city council on the development and oversight of parks facilities and recreational programming. The commission meets on the third Wednesday of the month at 7:30 p.m.

• Three seats on the Transportation and Public Safety Commission, which makes decisions on administrative and parking citations, and issues recommendations regarding the administration of public safety programs. The commission meets on the second and fourth Wednesdays of the month at 7:30 p.m.

Eligibility is open to Temple City residents. Commissioners serve without compensation. The City does cover commissioner costs for training and conferences as resources allow.

Applications can be downloaded on the City’s website, by email request to cityclerk@templecity.us, or by calling 626-285-2171 ext. 4132 during normal business hours. The deadline for submitting an application is 5 p.m. on Friday, April 28. The city council will select commissioners through an interview process.

For more information, call the city clerk’s office at (626) 285-2171, ext. 4132.

Publish April 3, 2023 TEMPLE CITY TRIBUNE

Duarte City Notices

Notice Of Inviting Bids

Bernards is requesting bids from qualified bidders for the Duarte High School Gymnasium – Phase 2 project located at 1565 Central Avenue, Duarte, CA 91010. The project consists of a new gymnasium. Construction includes grading and full construction of a new gym. We are interested in bids from all trades involved in this project minus demolition. The bidders will be selected using the “Best Value” competitive procurement process under California Education Code section 17400 et seq. “Best value” is a competitive procurement process whereby the selected bidder is selected on the basis of objective criteria for evaluating the qualifications of bidders with the resulting selection representing the best combination of price and qualifications.

Duarte High School Gymnasium – Phase 2

Bids Due: May 4, 2023 at 2:00pm

Email bids to: bid@bernards.com or to Gustavo Becerra at gbecerra@bernards.com

Pre-Qualification: In accordance with California Education Code 17250 and Public Contract Code 6109 all mechanical, electrical, plumbing (“MEP”) and sheet metal subcontractors (contractors that hold a C-4, C-7, C-10, C-16, C-20, C-34, C-36, C-38, C-42, C-43 or C-46 license), must have submitted prequalification applications (link below) at least ten (10) business days prior to bid date and must be approved at least five (5) business days PRIOR to bid date. Be sure to check approval and expiration dates. The prequalification application is available at the link below: https://www.duarteusd.org/cms/lib/CA01900906/Centricity/Domain/4/Duarte%20 HS%20Prequal%20Packet%202023.01.20.pdf

All prequalification applications must be completed and submitted to James Young at jyoung@ericksonhall.com and Mike Arnold at marnold@ericksonhall.com

Bernards is an Equal Opportunity Employer, committed to; and encourages the participation of MBEs, WBEs, DBEs, SBEs, DVBEs, and OBEs and requires submittal with their bid the certification form from the authorizing agency. Participation in Bernards’ Prequalification process improves our ability to collaborate with Subcontractors while providing them with the benefit of inclusion in potential select project lists. Please contact SubcontractorPrequalification@ bernards.com for Prequalification documents or visit our website https://www.bernards.com/industry-partners/ for more information. Subcontractors must comply with general prevailing wage rates (PCC 1720 et seq.). Under new California law, all subcontractors and sub-tier subcontractors wishing to conduct business with any public entity must be registered and maintain good standing with the Department of Industrial Relations (DIR) prior to submitting a bid and during performance of the work (Labor Code 1725.5). Only registered contractors and subcontractors can be awarded public works projects. Please visit www.dir.ca.gov/Public-Works/PublicWorks.html for more information and to register.

Subcontractors must also meet the minimum requirements for Skilled and Trained Workforce (PCC 2600 – 2603 et seq.). Also refer to California Education Code, Sections 81703(c)(2)(F) and 17407.5; Labor Code 1777.5; and CCR Title 8, Section 230.1. Please visit https://www.dir.ca.gov/Public-Works/Apprentices.html for more information.

Textura Construction Payment Management System: Subcontractors will be required to electronically sign and submit their pay applications – including invoices, sworn statements, conditional lien waivers, and unconditional lien waivers. Bernards pays for the majority of the cost for the Textura system. However, there is a small fee paid directly by each Subcontractor or Major Supplier to Textura which must be included in any bid to Bernards. For additional information and associated fees, please visit www.texturacorp.com.

Plans & Specifications: Plans and specifications will be available via BidMail and also the following link: https://share.bidmail.com/index.html#preconstruction/ sublist?project=200-176051

By submitting a bid, subcontractor confirms they have reviewed Bernards’ Standard Subcontract Agreement and/or Professional Service Agreement along with Attachments “A”, “B”, “C”, “D”, “E” and will execute said Agreement without modifications. Please review all Bernards’ Standard Subcontract documents and forms at https://share.bidmail.com/index.html#preconstruction/ sublist?project=200-176051. Bids that do not conform to these bid instructions will not receive the maximum number of subcontractor quality points in a “Best Value” award process. The Attachments will be issued via an addendum during the bid period.

All subcontractors awarded work on this project must be prepared to furnish 100% faithful performance and 100% payment bonds issued by a licensed, admitted corporate surety with a minimum A.M. Best rating of A-VI that is authorized to issue bonds by the State of California and is acceptable to Bernards, (current Treasury Listing is acceptable), in the full amount of their subcontracts.

Requests for Information: Due April 20, 2023 by 2:00pm to Matt Wopschall MWopschall@bernards.com

Non-Mandatory Job Walk: April 13, 2023 at 10:00am.

Publish April 3, 10, 2023

DUARTE DISPATCH

Probate Notices

NOTICE OF PETITION TO ADMINISTER ESTATE OF:

SCOTT G. COYKENDALL

CASE NO. 23STPB02999

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of SCOTT G. COYKENDALL.

A PETITION FOR PROBATE has been filed by YOULANDA DAVIS in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that YOULANDA DAVIS be appointed as personal representative to administer the estate of the decedent.

A HEARING on the petition will be held in this court as follows: 04/25/23 at 8:30AM in Dept. 29 located at 111 N. HILL ST., LOS ANGELES, CA 90012

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code.

Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner THOMAS O. HOFFMAN - SBN 100881

LAW OFFICES OF THOMAS O. HOFFMAN

302 W SIERRA MADRE BLVD SIERRA MADRE CA 91024 3/27, 3/30, 4/3/23

CNS-3683182# DUARTE DISPATCH

NOTICE OF PETITION TO ADMINISTER ESTATE OF VITO TANTILLO

Case No. 23STPB03025

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of VITO TANTILLO A PETITION FOR PROBATE has been filed by Jack N. Tantillo in the Superior Court of California, County of LOS ANGELES. THE PETITION FOR PROBATE requests that Jack N. Tantillo be appointed as personal representative to administer the estate of the decedent. THE PETITION requests authority