Starting a new business?

etBids and City’s website.

CITYWIDE SIDEWALK, CURB & GUTTER REPLACEMENTS

PROJECT No. 24009

Bidders shall attend a mandatory pre-bid meeting to acquaint Bidders with the contract requirements and site conditions that may affect the work. The mandatory pre-bid meeting will be held on Tuesday, April 4th, 2023 at 10:00 A.M. in the Rosemead Community Recreation Center at 3936 Muscatel Avenue. The City will only consider Bids submitted by those Bidders who attend the Mandatory Pre-Bid Meeting. All other bids will be considered non-responsive and subject to rejection.

The project consists of removal and replacement of concrete sidewalk, curb and gutter, driveway approaches, and curb ramps Citywide as indicated on the construction plans, including tree removals, tree replanting and other incidental and appurtenant work necessary for the proper completion of the project.

The engineer’s estimate for this project is in the range of $550,000. The successful bidder shall have THIRTY (30) working days to complete the work. Liquidated damages shall be $500.00 per calendar day. Copies of the Bidding and Contract Documents, Plans and Specifications can be obtained from the City’s PlanetBids portal. Contractors can register as a vendor and download the documents by visiting the PlanetBids Portal (https://pbsystem.planetbids.com/portal/54150/portal-home). Hard copy of the bid package will not be mailed.

SB 854 Requirements:

This project is subject to the requirements of SB 854. No prime contractor or subcontractor may be listed on a bid proposal for a public works project unless registered and qualified with the Department of Industrial Relations pursuant to Labor Code section 1725.5. No prime contractor or subcontractor may be awarded a contract for public work on a public works project unless registered and qualified with the Department of Industrial Relations pursuant to Labor Code section 1725.5. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. The bid proposal must include a printout from the DIR registration website showing that the prime contractor and each subcontractor is currently registered and qualified. No bid proposals will be accepted nor any contract entered into with a prime contractor without proof of registration as required above. [Unless within the limited exceptions from this requirement for bid proposals only under Labor Code Section 1771.1(a)]

Each bid must be accompanied by a bidder’s security in an amount not less than 10% of the amount of the bid, as a guarantee that the bidder will, if awarded the Contract, enter into a satisfactory agreement and provide a Performance Bond and a Payment Bond, each not less than 100% of the total amount of the bid price.

No bidder may withdraw his bid for a period of sixty-one (61) days after the above bid opening date.

FEDERAL CONTRACT PROVISIONS FOR COMMUNITY DEVELOPMENT BLOCK GRANT

Davis-Bacon Act and Copeland Anti-Kickback” Act.:

This contract will be funded in whole or in part with federal housing and community development funds. The Federal Labor Standards Provisions, including prevailing wage requirements of the DavisBacon and Related Acts will be enforced. To the extent this Contract is for construction services in excess of $2,000, the CONTRACTOR agrees at all times during the term of this Contract to comply with and abide by: (i) the terms of the Davis-Bacon Act(codified at 40 U.S.C. § 3141 et seq., as supplemented by regulations at 29 CFR Part 5), and that such terms and regulations are a part of this Contract and incorporated herein by this reference; and (ii) the terms of the Copeland “Anti-Kick Back” Act ( codified at 40 U.S.C. § 3145 et seq., as supplemented by 29 CFR 3), and that such terms and regulations are a part of this Contract and incorporated herein by this reference.

This project is a public work in the State of California, funded in whole or in part with public funds. Therefore, the higher of the two applicable prevailing wage rates, federal or state, will be enforced. The Contractor’s duty to pay State prevailing wages can be found under Labor Code Section 1770 et seq. Labor Code Sections 1775 and 1777.7 outline the penalties for failure to pay prevailing wages and to employ apprentices, including forfeitures and debarment. The State Wage Decision is on file at the City Clerk’s office, and is also available online at http://www.dir.ca.gov/dlsr/.

Apprenticeship Program:

Attention is directed to Sections 1777.5, 1777.6 and 1777.7 of the California Labor Code and Title 8, California Administrative code, Section 200 et seq. to ensure compliance and complete understanding of the law regarding apprentices.

Section 3 Statement:

To the extent this Project is funded in excess of $200,000, Section 3 regulations are required. Found under 24 CFR Part 75, the purpose of Section 3 is to ensure that employment and other economic opportunities generated by HUD financial assistance are, to the greatest extent feasible, directed to low- and very low-income persons, particularly those who are recipients of government assistance for housing.

Equal Employment Opportunity:

Except as otherwise provided under 41 CFR Part 60, to the extent this Contract meets the definition of a “federally assisted construction contract” as set forth in 41 CFR Part 60-1.3, the CONTRACTOR agrees at all times during the term of this Contract to comply with and abide by the following: (i) that the equal opportunity clause (“Equal Opportunity Clause”) is part of this Contract and incorporated herein by this reference in 41 CFR 60-1.4(b) in accordance with Executive Order 11246, “Equal Employment Opportunity” (30 FR 12319, 12935, 3 CFR Part, 1964-1965 Comp., p. 339), as amended by Executive Order 11375, “Amending Executive Order 11246 Relating to Equal Employment Opportunity,” and (ii) the regulations implementing the Equal Opportunity Clause at 41 CFR Part 60 and that such implementing regulations are a part of this Contract and incorporated herein by this reference.).

Debarment and Suspension Certification:

The Contractor certifies that neither Contractor nor any of Contractor’s agents, sub-contractors or employees who may perform services under this contract are debarred, suspended or excluded from participation in any federal assistance programs in accordance with Executive Orders 12549 and 12689 and its implementing guidelines. The Contractor agrees to immediately notify the Federal awarding agency if the Contractor or any of the Contractor’s agents, sub-contractors or employees who may perform services under this contract become debarred, suspended or excluded from participation in federal assistance programs or federal contract transactions.

Contract Work Hours and Safety Standards Act:

To the extent this Contract is in excess of $100,000 and involves the employment of mechanics or laborers, the Contractor agrees at all times during the term of this Contract to comply with and abide by the terms of the Contract Work Hours and Safety Standards Act, codified at 40 U.S.C. 3701 et seq., as supplemented by regulations at 29 CFR Part 5, and that such terms and regulations are a part of this Contract and incorporated herein by this reference.

Byrd Anti-Lobbying Amendment Certification:

To the extent this Contract is in excess of $100,000, the CONTRACTOR certifies that neither the CONTRACTOR nor any of the CONTRACTOR’s agents, sub-contractors or employees who may perform services under this Agreement have not used and will not use any Federally appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352. The CONTRACTOR agrees to immediately notify the Federal awarding agency if the CONTRACTOR or any of the CONTRACTOR’s agents, sub-contractors or employees who may perform services under this Agreement influence or attempt to influence any officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352.

Conflict of Interest:

In the procurement of supplies, equipment, construction, and services by sub-recipients, the conflict of interest provisions in 2 CFR 200.112 and 24 CFR 570.611, respectively, shall apply. No employee, officer or agent of the subrecipient shall participate in selection, or in the award or administration of a contract supported by Federal funds if a conflict of interest, real or apparent, would be involved. The Contractor represents, warrants and agrees that to the best of its knowledge, it does not presently have, nor will it acquire during the term of this Agreement, any interest direct or indirect, by contract, employment or otherwise, or as a partner, joint venture or shareholder (other than as a shareholder holding a one percent (1%) or less interest in publicly traded companies) or affiliate with any business or business entity that has entered into any contract, subcontract or arrangement with the City. Upon execution of this Agreement and during its term, as appropriate, the Contractor shall disclose in writing to the City any other contract or employment during the term of this Agreement by any other persons, business or corporation in which employment will or may likely develop a conflict of interest between the City’s interest and the interests of the third parties.

The CITY OF ROSEMEAD will affirmatively ensure the disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, disability, sex or national origin in the consideration for an award.

Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Compliance with the prevailing rates of wage and apprenticeship employment standards established by the State Director of Industrial Relations will be required.

Bidders shall be licensed in accordance with the provision of Chapter 9, Division 111 of the Business and Professions Code of the State of California. Bidder shall have a Class “A” license in good standing at the time Bids are received.

The Council reserves the right to reject any and all bids and to waive any informality, technical defect, or minor irregularity in any bid submitted.

An award of service shall not be final until the bids have been reviewed and a Contract Agreement with the City has been signed by the lowest responsible bidder and by the City.

Award of Contract Agreement is proposed for April 25th, 2023.

This project is funded in part by the U.S. Department of Housing and Urban Development (“HUD”). Consistent with federal regulations found in 24 CFR 135, participation on this contract is applicable to “Section 3” requirements pursuant to 24 CFR 135.3(d). Bidders shall refer to the Instructions to Bidders for additional information regarding “Section 3” requirements.

Dated this March 21, 2023

Ericka Hernandez City Clerk

Publish: March 23rd & 30th, 2023.

ROSEMEAD READER

Probate Notices

NOTICE OF PETITION TO ADMINISTER ESTATE OF: HARALD GANSERT; AKA HARALD ALBIN GANSERT; HARALD A. GANSERT; HAROLD A. GANSERT; HARALD ALWIN GANSERT CASE

NO. 23STPB02804

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of HARALD GANSERT; AKA HARALD ALBIN GANSERT; HARALD A. GANSERT; HAROLD A. GANSERT; HARALD ALWIN GANSERT.

A PETITION FOR PROBATE has been filed by COUNTY OF LOS ANGELES PUBLIC ADMINISTRATOR in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that COUNTY OF LOS ANGELES PUBLIC ADMINISTRATOR be appointed as personal representative to administer the estate of the decedent.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act with limited authority. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held in this court as follows: 04/21/23 at 8:30AM in Dept. 11 located at 111 N. HILL ST., LOS ANGELES, CA 90012

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner

LINDA ESHOE - SBN 159481, PRINCIPAL DEPUTY COUNTY COUNSEL, OFFICE OF THE LOS ANGELES COUNTY COUNSEL 500 W. TEMPLE STREET, SUITE 652 LOS ANGELES CA 90012 3/23, 3/27, 3/30/23 CNS-3682166# TEMPLE CITY TRIBUNE

NOTICE OF PETITION TO ADMINISTER ESTATE OF:

FREDERICK IBARRA, JR.

CASE NO. 23STPB02651

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of FREDERICK IBARRA, JR.

A PETITION FOR PROBATE has been filed by GLORIA TOMESITA CARRILLO in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that GLORIA TOMESITA CARRILLO be appointed as personal representative to administer the estate of the decedent.

THE PETITION requests the decedent's WILL and codicils, if any, be admitted to probate. The WILL and any codicils are available for examination in the file kept by the court.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held in this court as follows: 04/14/23 at 8:30AM in Dept. 5 located at 111 N. HILL ST., LOS ANGELES, CA 90012

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Attorney for Petitioner MARC P. GRISMER - SBN 300270, LAW OFFICE OF MARC P. GRISMER 9901 PARAMOUNT BLVD., SUITE 222 DOWNEY CA 90240

3/23, 3/27, 3/30/23

CNS-3682862# EL MONTE EXAMINER

NOTICE OF PETITION TO ADMINISTER ESTATE OF TAM MA

Case No. 23STPB02818

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of TAM MA

A PETITION FOR PROBATE has been filed by Tri Huu Ma in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that Tri Huu Ma be ap-pointed as personal representative to administer the estate of the dece-dent.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administra-tion authority will be granted unless an interested person files an objec-tion to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held on April 26, 2023 at 8:30 AM in Dept. No. 2D located at 111 N. Hill St., Los Angeles, CA 90012.

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your ap-pearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code.

Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowl-edgeable in California law. YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for petitioner: DAVID SEAN DUFEK ESQ

SBN 193723

LAW OFFICE OF DAVID SEAN DUFEK 3772 CLAIREMONT DR SAN DIEGO CA 92117

CN994960 MA

Mar 23,27,30, 2023 EL MONTE EXAMINER

NOTICE OF PETITION TO ADMINISTER ESTATE OF Mui Sam Pun

CASE NO. 23STPB01517

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of: Mui Sam

Pun

A PETITION FOR PROBATE has been filed by Nam Su Hoang in the Superior Court of California, County of Los Angeles.

THE PETITION FOR PROBATE requests that Nam Su Hoang be appointed as personal representative to administer the estate of the decedent.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act with full authority . (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held on 04/26/2023 at 8:30 AM in Dept. 11 located at 111 N. HILL ST. LOS ANGELES CA 90012 STANLEY MOSK COURTHOUSE.

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner: Cindy Nguyen, Esq., 273886

Amity Law Group, LLP

3733 Rosemead Blvd, Suite 201

Rosemead, CA 91770, Telephone: (626) 307-2800 3/23, 3/27, 3/30/23

CNS-3683458# ROSEMEAD READER

NOTICE OF PETITION TO ADMINISTER ESTATE OF VITO TANTILLO

Case No. 23STPB03025

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of VITO TANTILLO

A PETITION FOR PROBATE has been filed by Jack N. Tantillo in the Superior Court of California, County of LOS ANGELES. THE PETITION FOR PROBATE requests that Jack N. Tantillo be appointed as personal representative to administer the estate of the decedent. THE PETITION requests author- ity to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.)

The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held on April 25, 2023 at 8:30 AM in Dept. 44. located at 111 N. Hill St., Los Angeles, CA 90012.

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for petitioner:

STEPHEN P. JANIS SBN 237375

BANKS, GARCIA & JANIS

10788 CIVIC CENTER DRIVE RANCHO CUCAMONGA, CA 91730 (909) 980 – 3795 MARCH 27, 30, APRIL 3, 2023 SAN GABRIEL SUN

NOTICE OF PETITION TO ADMINISTER ESTATE OF: SCOTT G. COYKENDALL CASE NO. 23STPB02999

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of SCOTT G. COYKENDALL.

A PETITION FOR PROBATE has been filed by YOULANDA DAVIS in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that YOULANDA DAVIS be appointed as personal representative to administer the estate of the decedent.

A HEARING on the petition will be held in this court as follows: 04/25/23 at 8:30AM in Dept. 29 located at 111 N. HILL ST., LOS ANGELES, CA 90012

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk. Attorney for Petitioner