Starting a new business?

Rosemead City Notices

City Of Rosemead

NOTICE INVITING BIDS NIB No. 2023-08

NOTICE IS HEREBY GIVEN that the CITY OF ROSEMEAD, California, will receive electronic bids through PlanetBids at: https:// pbsystem.planetbids.com/portal/54150/portal-home OR sealed bids at the City Clerk’s office, City Hall, 8838 Valley Blvd, Rosemead, CA 91770 up to 10:30 o’clock a.m. on Tuesday, the 18th day of April, 2023. Electronic and hardcopy bids will be publicly posted on PlanetBids and City’s website.

ARTERIAL STREET PAVEMENT REHABILITATION PROJECT No. 43010

The project consists of removing and replacing existing AC Pavement, adjusting manhole covers, water valve covers, and gas covers to grade. Project also includes removal and replacement of raised pavement markers, striping, and traffic signal loops to match existing, as well as miscellaneous work as indicated on the construction plans, including other incidental and appurtenant work necessary for the proper completion of the project.

The engineer’s estimate for this project is in the range of $3,500,000. The successful bidder shall have THIRTY (30) working days including material procurement to complete the work. Liquidated damages shall be $500.00 per calendar day.

Copies of the Bidding and Contract Documents, Plans and Specifications can be obtained from the City’s PlanetBid portal. Contractors can register as a vendor and download the documents by visiting the PlanetBid Portal (https://pbsystem.planetbids.com/ portal/54150/portal-home). Hard copy of the bid package will not be mailed.

SB 854 Requirements:

This project is subject to the requirements of SB 854. No prime contractor or subcontractor may be listed on a bid proposal for a public works project unless registered and qualified with the Department of Industrial Relations pursuant to Labor Code section 1725.5. No prime contractor or subcontractor may be awarded a contract for public work on a public works project unless registered and qualified with the Department of Industrial Relations pursuant to Labor Code section 1725.5. This project is subject to compliance monitoring and enforcement by the Department of Industrial Relations. The bid proposal must include a print out from the DIR registration website showing that the prime contractor and each subcontractor is currently registered and qualified. No bid proposals will be accepted nor any contract entered into with a prime contractor without proof of registration as required above. [Unless within the limited exceptions from this requirement for bid proposals only under Labor Code Section 1771.1(a)]

Each bid must be accompanied by a bidder’s security in an amount not less than 10% of the amount of the bid, as a guarantee that the bidder will, if awarded the Contract, enter into a satisfactory agreement and provide a Performance Bond and a Payment Bond, each not less than 100% of the total amount of the bid price.

No bidder may withdraw his bid for a period of sixty-one (61) days after the above bid opening date.

The CITY OF ROSEMEAD will affirmatively ensure the disadvantaged business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, disability, sex or national origin in the consideration for an award.

Any contract entered into pursuant to this notice will incorporate the provisions of the State Labor Code. Compliance with the prevailing rates of wage and apprenticeship employment standards established by the State Director of Industrial Relations will be required.

Bidders shall be licensed in accordance with the provision of Chapter 9, Division 111 of the Business and Professions Code of the State of California. Bidder shall have a Class “A” license in good standing at the time Bids are received.

The Council reserves the right to reject any and all bids and to waive any informality, technical defect, or minor irregularity in any bid submitted.

An award of service shall not be final until the bids have been reviewed and a Contract Agreement with the City has been signed by the lowest responsible bidder and by the City.

Award of Contract Agreement is proposed for April 25th, 2023.

All questions regarding this bid shall be uploaded City’s portal on PlanetBids, no later than 10 calendar days prior to bid due date and time.

Dated this March 23, 2023

Ericka Hernandez City Clerk

Publish: March 27th & April 3rd, 2023. ROSEMEAD READER

Probate Notices

NOTICE OF PETITION TO ADMINISTER ESTATE OF TORIBIO BAEZ A.K.A. TORIBIO BAEZ VILLA

CASE NO. 23STPB02617

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the LOST will or estate, or both, of: TORIBIO BAEZ A.K.A. TORIBIO BAEZ VILLA

A PETITION FOR PROBATE has been filed by CRISTIAN BAEZ in the Superior Court of California, County of Los Angeles.

THE PETITION FOR PROBATE requests that CRISTIAN BAEZ be appointed as personal representative to administer the estate of the decedent.

THE PETITION requests the decedent’s LOST WILL and codicils, if any, be admitted to probate. The LOST will and any codicils are available for examination in the file kept by the court.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act with full authority . (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held on 04/25/2023 at 8:30 AM in Dept. 79 located at 111 N. HILL ST. LOS ANGELES CA 90012 STANLEY MOSK COURTHOUSE,STANLEY MOSK COURTHOUSE.

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner:

Clayton D. Wilson SB# 40339, Wilson & Wilson, 414 S. First Ave., Arcadia, CA 91006, Telephone: (626) 574-1890 3/20, 3/23, 3/27/23 CNS-3681350# AZUSA BEACON

NOTICE OF PETITION TO ADMINISTER ESTATE OF: FREDERICK IBARRA, JR. CASE NO. 23STPB02651

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of FREDERICK IBARRA, JR.

A PETITION FOR PROBATE has been filed by GLORIA TOMESITA CARRILLO in the Superior Court of California, County of LOS ANGELES. THE PETITION FOR PROBATE requests that GLORIA TOMESITA CARRILLO be appointed as personal representative to administer the estate of the decedent.

THE PETITION requests the decedent’s WILL and codicils, if any, be admitted to probate. The WILL and any codicils are available for examination in the file kept by the court.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act. (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held in this court as follows: 04/14/23 at 8:30AM in Dept. 5 located at 111 N. HILL ST., LOS ANGELES, CA 90012

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner

MARC P. GRISMER - SBN 300270, LAW OFFICE OF MARC P. GRISMER 9901 PARAMOUNT BLVD., SUITE 222 DOWNEY CA 90240 3/23, 3/27, 3/30/23

CNS-3682862# EL MONTE EXAMINER

NOTICE OF PETITION TO ADMINISTER ESTATE OF:

SCOTT G. COYKENDALL CASE NO. 23STPB02999

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of SCOTT G. COYKENDALL.

A PETITION FOR PROBATE has been filed by YOULANDA DAVIS in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that YOULANDA DAVIS be appointed as personal representative to administer the estate of the decedent.

A HEARING on the petition will be held in this court as follows: 04/25/23 at 8:30AM in Dept. 29 located at 111 N. HILL ST., LOS ANGELES, CA 90012

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner THOMAS O. HOFFMAN - SBN 100881

LAW OFFICES OF THOMAS O. HOFFMAN 302 W SIERRA MADRE BLVD SIERRA MADRE CA 91024

3/27, 3/30, 4/3/23

CNS-3683182#

DUARTE DISPATCH

NOTICE OF PETITION TO ADMINISTER ESTATE OF Mui Sam Pun

CASE NO. 23STPB01517

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of: Mui Sam Pun

A PETITION FOR PROBATE has been filed by Nam Su Hoang in the Superior Court of California, County of Los Angeles.

THE PETITION FOR PROBATE requests that Nam Su Hoang be appointed as personal representative to administer the estate of the decedent.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act with full authority . (This authority will allow the personal representative to take many actions without obtaining court approval. Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held on 04/26/2023 at 8:30 AM in Dept. 11 located at 111 N. HILL ST. LOS ANGELES CA 90012 STANLEY MOSK COURTHOUSE.

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner: Cindy Nguyen, Esq., 273886

NOTICE OF PETITION TO ADMINISTER ESTATE OF: HARALD GANSERT; AKA HARALD ALBIN GANSERT; HARALD A. GANSERT; HAROLD A. GANSERT; HARALD ALWIN GANSERT CASE NO. 23STPB02804

To all heirs, beneficiaries, creditors, contingent creditors, and persons who may otherwise be interested in the WILL or estate, or both of HARALD GANSERT; AKA HARALD ALBIN GANSERT; HARALD A. GANSERT; HAROLD A. GANSERT; HARALD ALWIN GANSERT.

A PETITION FOR PROBATE has been filed by COUNTY OF LOS ANGELES PUBLIC ADMINISTRATOR in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that COUNTY OF LOS ANGELES PUBLIC ADMINISTRATOR be appointed as personal representative to administer the estate of the decedent.

THE PETITION requests authority to administer the estate under the Independent Administration of Estates Act with limited authority. (This authority will allow the personal representative to take many actions without obtaining court approval.

Before taking certain very important actions, however, the personal representative will be required to give notice to interested persons unless they have waived notice or consented to the proposed action.) The independent administration authority will be granted unless an interested person files an objection to the petition and shows good cause why the court should not grant the authority.

A HEARING on the petition will be held in this court as follows:

04/21/23 at 8:30AM in Dept. 11 located at 111 N. HILL ST., LOS ANGELES, CA 90012

IF YOU OBJECT to the granting of the petition, you should appear at the hearing and state your objections or file written objections with the court before the hearing. Your appearance may be in person or by your attorney.

IF YOU ARE A CREDITOR or a contingent creditor of the decedent, you must file your claim with the court and mail a copy to the personal representative appointed by the court within the later of either (1) four months from the date of first issuance of letters to a general personal representative, as defined in section 58(b) of the California Probate Code, or (2) 60 days from the date of mailing or personal delivery to you of a notice under section 9052 of the California Probate Code. Other California statutes and legal authority may affect your rights as a creditor. You may want to consult with an attorney knowledgeable in California law.

YOU MAY EXAMINE the file kept by the court. If you are a person interested in the estate, you may file with the court a Request for Special Notice (form DE-154) of the filing of an inventory and appraisal of estate assets or of any petition or account as provided in Probate Code section 1250. A Request for Special Notice form is available from the court clerk.

Attorney for Petitioner

LINDA ESHOE - SBN 159481, PRINCIPAL DEPUTY COUNTY COUNSEL, OFFICE OF THE LOS ANGELES COUNTY COUNSEL 500 W. TEMPLE STREET, SUITE 652 LOS ANGELES CA 90012 3/23, 3/27, 3/30/23 CNS-3682166# TEMPLE CITY TRIBUNE

NOTICE OF PETITION TO ADMINISTER ESTATE OF TAM MA

Case No. 23STPB02818

To all heirs, beneficiaries, cred-itors, contingent creditors, and persons who may otherwise be interested in the will or estate, or both, of TAM MA

A PETITION FOR PROBATE has been filed by Tri Huu Ma in the Superior Court of California, County of LOS ANGELES.

THE PETITION FOR PROBATE requests that Tri Huu Ma be ap-pointed as personal representa-